Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
2013-08-8054
ORDINANCE NO. 2013-8-8054 AN ORDINANCE OF THE CITY OF PADUCAH, KENTUCKY, APPROVING THE AIA DESIGN -BUILD CONSTRUCTION AGREEMENT, AS AMENDED AND SUPPLEMENTED AMONG THE CITY OF PADUCAH, KENTUCKY, THE COUNTY OF MCCRACKEN, KENTUCKY, AND A&K CONSTRUCTION, INC., WITH RESPECT TO A PUBLIC PROJECT; AUTHORIZING THE EXECUTION OF THE AIA DESIGN -BUILD CONSTRUCTION AGREEMENT AND OTHER DOCUMENTS RELATED THERETO WHEREAS, the City of Paducah, Kentucky (the "City") has previously determined, and hereby further determines, that it is a public purpose to reduce unemployment in the City, to increase the City's tax base, to foster economic development within the City and to promote the development of a skilled workforce, all to the benefit of the citizens and residents of the City; and WHEREAS, by Ordinance No. 2012-11-7986 adopted by the City Commission on November 13, 2012, the City previously declared its support for an economic development project initiated by G.P.E.D.C., Inc., ("GPEDC") with TeleTech Services Corporation ("TeleTech") to develop and locate general and administrative offices for customer care centers that will bring approximately 450 new full time jobs ("Project") in Paducah, Kentucky, within the boundaries of Paducah, McCracken County, Kentucky. WHEREAS, by Municipal Order No. 1716, adopted by the City Commission on March 26, 2013, and Interlocal Cooperative Agreement dated April 8, 2013 among the City and McCracken County, Kentucky (the "County"), the City and County, with the assistance of G.P.E.D.C. Inc., ("GPEDC") agreed to assumed the obligation of GPEDC under that certain lease agreement with TeleTech dated January 1, 2013 (the "Lease") and related Memorandum of Understanding ("MOU") dated November 1, 2012, also among GPEDC and TeleTech to construct and install a customer care center with a construction allowance of $3,000,000.00; and WHEREAS, as a result of the foregoing, the City, the County, and A&K Construction, Inc. ("A&K"), find it necessary and advisable that the City now authorize the AIA Design -Build Construction Agreement, as amended and supplemented, among City, County, and A&K with respect to the Project. NOW THEREFORE, BE IT ORDAINED BY THE CITY COMMISSION OF THE CITY OF PADUCAH, KENTUCKY, AS FOLLOWS: Section 1. Recitals and Authorization. The City hereby approves the AIA Design -Build Construction Agreement, as amended and supplemented, among City, County, and A&K (the "Agreement") in substantially the form attached hereto as Exhibit A and made part hereof. It is further determined that it is necessary and desirable and in the best interest of the City to enter into the Agreement for the purposes therein specified, and the execution and delivery of the Agreement is hereby authorized and approved. The Mayor of the City is hereby authorized to execute the Agreement, together with such other agreements, instruments or certifications which may be necessary to accomplish the transaction contemplated by the Agreement with such changes in the Agreement not inconsistent with this Ordinance and not substantially adverse to the City as may be approved by the official executing the same on behalf of the City. The approval of such changes by said official, and that such are not substantially adverse to the City, shall be conclusively evidenced by the execution of such Agreement by such official. Section 2. Severability. If any section, paragraph or provision of this Ordinance shall be held to be invalid or unenforceable for any reason, the invalidity or unenforceability of such section, paragraph or provision shall not affect any of the remaining provisions of this Ordinance. Section 3. Compliance With Open Meetings Laws. The City Commission hereby finds and determines that all formal actions relative to the adoption of this Ordinance were taken in an open meeting of this City Commission, and that all deliberations of this City Commission and of k ,I..,. . , LUJ.��L...— :� -'-J _.aW � r.. .t_ LL - _ I a::_ 'A i— I _ -A - I I .. _. .-11 ,:: I its committees, if any, which resulted in formal action, were in meetings open to the public, in full compliance with applicable legal requirements. Section 4. Conflicts. All ordinances, resolutions, orders or parts thereof in conflict with the provisions of this Ordinance are, to the extent of such conflict, hereby repealed and the provisions of this Ordinance shall prevail and be given effect. Section 5. Effective Date. This Ordinance shall be read on two separate days and will become effective upon summary publication pursuant to KRS Chapter 424. A TEST: Tammara S. Sanderson, City Clerk Introduced by the Board of Commissioners, July 23, 2013 Adopted by the Board of Commissioners, July 30, 2013 Recorded by Tammara S_ Sanderson, City Clerk, July 30, 2013 Published by The Paducah Sun, August 13, 2013 \word\ord\Agree-TeleTech Construction EXHIBIT A THE AIA DESIGN -BUILD CONSTRUCTION AGREEMENT, AS AMENDED AND SUPPLEMENTED See attachment. iSAIA Document A141Ta - 2004 Standard Form of Agreement Between Owner and Design -Builder AGREEMENT made as of the day of in the year (In words, indicate day, month and year.) BETWEEN the Owner: ADDITIONS AND DELETIONS: (Name, legal status address and other information) The author of this document has added information needed for Its City of Paducah and County of McCracken County completion. The author may also have revised the text of the original AIA standard form. An Additions and Deletions Report that notes added Information as well as revisions to the standard form text is available from and the Design -Builder: the author and should be reviewed. A (Name, legal status, address and other information) vertical line in the left margin of this Construction, Inc. document Indicates where the author 100 loo Calloway Court has added necessary Information Paducah, KY 42001 and where the author has added to or deleted from the original AIA text. This document has important legal consequences. Consultation with an for the following Project: attorney Is encouraged with respect (Name, location and detailed description) to its completion or modification. Teletech Call Center 2301 McCracken Boulevard Consultation with an attorney is also Paducah, KY 42001 encouraged with respect to professional licensing requirements in the jurisdiction where the Project Is The Owner and Design -Builder agree as follows. located. Init. A,c t3 -- --- - -- — -- t,r rine-,:is. All riyh m "rvq(j. N.h4y ,yG "r hl s A Ft' tk;rr;mar , I +t reprMitet<,. b•, secrete civil and criminar " `' ' r:f' '�c1°; ..' r: d t;:�;�;rail of !nU Ik t•acu :tr:, y, any poriion of i:, mai rG:;GiI u+ 13 17:41 on 06/25/2 derOr of arta will 8 pro ,cooled to the maximum extent possible ander the lav, This document was produced byA.lA soitvtare at y 012 under Grder No.5278369107 i which expire on 10/16/2012, and is not for resale User (Votesr - (,U97684601) I r� TABLE OF ARTICLES 1 THE DESIGN -BUILD DOCUMENTS 2 WORK OF THIS AGREEMENT 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 4 CONTRACTSUM 5 PAYMENTS 6 DISPUTE RESOLUTION 7 MISCELLANEOUS PROVISIONS 8 ENUMERATION OF THE DESIGN -BUILD DOCUMENTS TABLE OF EXHIBITS A TERMS AND CONDITIONS B DETERMINATION OF THE COST OF THE WORK C INSURANCE AND BONDS ARTICLE 1 THE DESIGN -BUILD DOCUMENTS § 1.1 The Design -Build Documents form the Design -Build Contract. The Design -Build Documents consist of this Agreement between Owner and Design -Builder (hereinafter, the "Agreement") and its attached Exhibits; Supplementary and other Conditions; Addenda issued prior to execution'ofthe Agreement; the Project Criteria, including changes.t.o the project Criteria proposed by the Design -Builder and accepted by the.Owrier, ifany; the Design -Builder's Proposal and written Wodif cations to the Proposal -accepted by the Owner, ifany; other documents listed in this Agreement; and Modifications issued after execution of this Agreement. The Design -Build Documents shall not be construed to create a contractual relationship of any kind (1) between the Architect and Owner, (2) between the Owner and a Contractor or Subcontractor, or (3) between any persons or entities other than the Owner and Design -Builder, including but not limited to any consultant retained by the Owner to prepare or review the Project Criteria. An enumeration of the Design -Build Documents, other than Modifications, appears in Article 8. § 1.2 The Design -Build Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. § 1.3 The Design -Build Contract may be amended or modified only by a Modification. A Modification is (1) a written amendment to the Design -Build Contract signed by both parties, (2) a Change Order, (3) a Construction Change Directive or (4) a written order for a minor change in the Work issued by the Owner. ARTICLE 2 THE WORK OF THE DESIGN -BUILD CONTRACT § 2.1 The Design -Builder shall fully execute the Work described in the Design -Build Documents, except to the extent specifically indicated in the Design -Build Documents to be the responsibility of others. ARTICLE 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be the date of this Agreement unless a different date is stated below or provision is made for the date to be fixed in a notice issued by the Owner. (Insert the date of commencement if it differsfrom the date of this Agreement or, if applicable, state that the date will be fired in a notice to proceed.) J [nit AIA �r.,cumar.i r i.; 1 ��° - st ter. Cop,r;3ht sa2-r4 Dy Me I nencan inahtule or?trcA�taCiB. All rights resarved. `rrAk!lI fl -w, A;A` Oucun:2nt is pry t� Cauy:'ig Y.+ t.2:! :•., r) In tertl7.tion3t Tr•?stir {J+' eu!h ,:ri2 F.ri ;seer , or eat °• (•; ... ,. ::: r;• ., stefht�l, un n.t than, p .,. �......t s:.� G:r;•t'. :' I:, ❑:;;� '...r severe ci-ii annu d criaal penalties. and Iv be prosecuted to the mixirnum extent oossible under the law. This docuc:; ment was produced by AIA soras:•ftvvareaf 1 13:17:41 on 06/25/2012 under Order No 327636410' 1 which expires on 10116120 1 2, and is not for resale User Notes: (1097684601) —,-1 . , --4, r w . -- �_� — L 1 — _ -L— _�IdL 11 I 1I, prior to tate commencement of Work, the -Owner requires time to file mortgages, documents related to mechanic's tiers and other security -interests, the Owner's time requirement shall be as follows: (Insert Clwner's•timee requirements.) § 3.2 The Contract Timeshall be measured from the date of commencement, subject to adjustments of this Contract Time as provided in the Design-Opild Documents. (Insert pravisiorts, f arta, for liquid 100 d4mages relating to failure to complete on time or for bonus payments for early completion ofthe Work) s § 3.3 The Design -Builder shall achieve Substantial Completion of the Work not later than days from the date of commencement, or as follows: (Insert number of calendar days Alternatively, a calendar date may be used when coordinated with the date of commencement. Unless stated elsewhere in the Design Build Documents, insert any requirements for earlier Substantial Completion of certain portions of the Work.) Portion of Work Substantial Completion Date ARTICLE 4 CONTRACT SUM § 4^1 The Ownei':"il paythe Design -Builder the Contract Sum in current funds for the Design -Builder's perfomn'ancd aftfi&De W4 Build Contract. The Contract Stun shall be one of the following: (check the appropriate 66x.) [ ) Stipulated Sum in accordance with Section 4.2 below; [ j Cost of the Work Plus Design -Builder's Fee in accordance with Section 4.3 below; [X ). Cost of the Work Plus Design -Builder's Fee with a Guaranteed Maximum Price in accordance with Section 4.4 below. (Based on the selection above, complete either Section 4.2, 4.3 or 4.4 below.) § 4.2 STIPULATED SUM § 4.2.1 The Stipulated Sum shall be (S ), subject to additions and deductions as provided in the Design -Build Documents. § 4.2.2 The Stipulated Sum is based upon the following alternates, if any, which are described in the Design -Build Documents and are hereby accepted by the Owner: § 4.2.3 Unit prices, if any, areas follows: Description Units Price ($4.00) § 4.2.4 Allowances, if any, are as follows: (lden105` and state the amounts of'any allowances, and state whether they include lalbor, materials, or both.) ri :._ Enrt :Al" i.ol•y 'tan: yR 200•: by ifieA,ner.rart IM, 1W. J! A,CH11QGts, All __—__-- C:gl'ry rl.; ; +v: xo<} �n!;a�,:8?;^•::; T^Rg11 kjn; rl�hlS rQ SafVad t it •• f.- 4' :. R.u.,.,,e I<. Gr�� /. tN i_.ri sever civic and n'CiS >: r::r.y':r:;i: i''7 r..; •ila.C,:I. C'thc: dl,',• ih,.. •:r, t s; -.. :i. r.... :: Wt, 1cs.U: 13'17:41 on 06/26!2:912 u ., LI -012 u penalti7..,. es. and will be prosecuted hm ,.) tho ae.irnum extant posaipto under the 61"1 This docutneni was produced by AIA soltwdr0 at 3 User Notes: / under order No 527536910? —1 which expires on 10/18!2012, and is not For r=;ate (1097684501) Allowance Amount ($0.00) Included Items § 4.2.5 Assumptions or qualifications, if any, on which the Stipulated Stun is based, are as follows: § 4.3 COST OF THE WORK PLUS DESIGN -BUILDER'S FEE § 4.3.1 The Cost of the Work is as defined in Exhibit B. § 4.3.2 The Design -Builder's Fee is: (State a lump sum, percentage ofCost of the Work or other provision for determining the Design -Builder's Fee and the method of adjustment to the Fee for changes in the Work.) § 4.4 COST OF THE WORK PLUS DESIGN -BUILDER'S FEE WITH A GUARANTEED MAXIMUM PRICE § 4.4.1 The Cost of the Work is as defined in Exhibit B, plus the Design -Builder's Fee. § 4.4.2 The Design -Builder's Fee is: tS141e a lump sum,..jw. ntpge pj!.`CO..st of the Work or other provision for determining the Design -Builder's Fee and dw method :ofgrldtisttment0 t'he Fee for changes in the Work.) ($3,296,000.00) Three mil lion two hundred ninety-six thousand dollars § 4.4.3 GU. NTEED iNAXIMUM PRICE § 4.4.3.1 Th rum rof the'Gosf of the -Work and the Design -Builder's Fee is guaranteed by the Design -Builder not to exceed ($ I Subject to arttljtidrts: ancl.deduetions by changes in the Work as provided in the Design -Build Documetifs. •Such maximwn sum. is refelrred 0111 the Design -Build Documents as the Guaranteed Maximum Price. Costs which would cause the Guaranteed Maximum Price to be exceeded shall be paid by the Design -Builder without reimbursement by the Owner. (Insert specific provisions if the Design -Builder is to participate in any savings) § 4.4.3.2 The Guaranteed Maximum Price is based on the following alternates, if any, which are described in the Design -Build Documents and are hereby accepted by the Owner: § 4.4.3.3 Unit Prices, if any, are as follows: Description Units Price ($0.00) § 4.4.3.4 Allowances, if any, are as follows: (Identify and .state the amounts of arty allowances, and state whether they include labor, materials, or both.) Allowance Amount ($0.00) Included Items § 4.4,3.5 Assumptions, if any, on which the Guaranteed Maximum Price is based, are as follows: (Identify t& assumptions on which the Guaranteed Maximum Price is based.) (reit AIA Go cumerr Aldi 2004. Gopyright02034 byT heAmerican hu:Otule otArctittacts. Alt )ighN reserved. WARUNG i'!iI5 P.IA' po�:umer! :u prVt�cten py y- US Co,)yrly7nt t.8 r.:!n;! !Irtlri IUUrt 3! Tr att G=: Unaulhwi7! d teilrod.'Jr!lon o: distribution of till, Ai.tt • c:;mCr,i. cr,iry port:Grt n! It. ,nxy r6aun lri sC+, 4'fY• Gr'dll dPt! crtrn�r,:v y,ereaples, �n .alll i. li::i :c utE r7 tv. Mr. (nax"'now. exk ml Q9@2itlle Irnder',pb taw T.Ns: yot.un':?ni evd5 p:[�)u,^,r:10y d4A. swiwa!, vt i ser :41 on 08,'2572f)42 ander ;der hJo 62%5 3 7:) w!ttCi! ex�irai on 10;55!?0t2, aro:i is tnt.or r_sale ;ills"r6&4&D5! § 4.5 CHANGES IN THE WORK § 4.5.1 Adjustments ofthe Contract sum on account of changes in the Work may be determined by any ofthe methods listed in Article A.7 of Exhibit A, Terms and Conditions. § 4.5.2 Where the Contract Sum is the Cost ofthe Work, with or without a Guaranteed Maximum Price, and no specific provision is made in Sections 4.3.2 or 4.4.2 for adjustment of the Design -Builder's Fee in the case of Changes in the Work, or if the extent ofsuch•changes is such, in the aggregate, that application oftha adjustment will cause substantial inequity to the Owner Or Design -Builder, the Design -Builder's Fee shall be equitably adjusted on the basis of the Fee established for the original Wark; and the Contract Sum shall be adjusted accordingly, ARTICLE 5 PAYMENTS § 5.1 PROGRESS PAYMENTS § 5.1.1 Based upon Applications for Payment submitted to the Owner by the Design -Builder, the Owner shall make Progress payments on account of the Contract Sum to the Design -Builder as provided below and elsewhere in the Design -Build Documents. § 5.1.2 The period, covered by each Application for Payment shall be one calendar month ending on the last day of the month, or as follows: 7th following 7th § 5,1.3 Provided that an Application for Paytnes receive of later than the " d4y of month, the Owner shall make payment to the pe9rgn rider not later thaif the l day of the I Month. [fan Applicatibir for Payirient is received by the Owner after the application date fixed above; p"dlftt "shall be tirade by the OyAier riot later tha V,(3o) days after the Owner reeeives the Applicatign for i'syment, thirty 5.1A With each Application. for. Payment where the Contract Sum is based upas the Cost ofthe Work, or the Cost of the Vlrock with:a ua e- ... Arleximum Price, the, Uesigii!80100 "submit payfbIh,.pett}ccash accounts, receipted invoices or invoices *ith check vouchers attac#teit, t3nd any other evidence reg6ked by-theOwner to.demonstrate that cash disbitrsetnedt§ already Made 5y theDent n -Builder oil accoufit of slid Grist df the Wbik equal or exceed (1) Progress payments already received by the Design -Builder, less (2) that portion of those payments attributable to the Design -Builder's Fee; plus (3) payrolls for the period covered by the present Application for Payment. § 5.1.5 With each Application for Payment where the Contract Sum is based upon a Stipulated Sum or Cost of the Work with a Guaranteed Maximum Price, the Design -Builder shall submit the most recent schedule of values in accordance with the Design -Build Documents. The schedule of values shall allocate the entire Contract Sum among the various portions of the Work. Compensation for design services shall be shown separately. Where the Contract Sum is based on the Cost of the Work with a Guaranteed Maximum Price, the Design -Builder's Fee shall be shown separately. The schedule of values shall be prepared in such form and supported by such data to substantiate its accuracy as the Ovmer may require. This schedule of values, unless objected to by the Owner, shall be used as a basis for reviewing the Design-BuildeCs Applications for Payment. § 5.1.6 In taking action on the Design -Builder's Applications for Payment, the Owner shall be entitled to rely on the accuracy and completeness of the information furnished by the Design -Builder and shall not be deemed to have made a detailed examination, audit or arithmetic verification of the documentation submitted in accordance with Sections 5.1.4 or 5.1.5, or other supporting data; to have made exhaustive or continuous on-site inspections; or to have made examinations to ascertain how or for what purposes the Design -Builder has used amounts previously paid on account ofthe Agreement. Such examinations, audits and verifications, if required by the Owner, will be perForrned by the Owner's accountants acting in the sole interest ofthe Owner. § 5.1.7 Except with the Owner's prior approval, the Design -Builder shall not make advance payments to suppliers for materials or equipment which have not been delivered and stored at the site. § 5.2 PROGRESS PAYMENTS - STIPULATED SUNT § 5.2.1 Applications for Payment where the Contract Sun is based upon a Stipulated Sum shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. ca s•1gl;lo-:c C Alctn'e0i. All rl4 h - • '•-.:� _: . !:,t•+.::nH,. ,! i-. _. ... sr,. .s:. - - er. rtTtturvod. ", =.a,.•; :qr; Irn, : s ", _ :.,,•::..,, ,.,:.;,, ... .. _�' se"• r civil s;,a c :roirsal pen_illies, and wia be; prosecuted tt, tn<;'maximurn extent pussible under thq saw This docurnens � ds croduced bV AIA sof-woa at t 13.17:41 an Uo"125".!2012 under order t }0 527@35910% 1 which expires on 1 011 6120 1 2. and is not for resale 11aer Notes: - (IU9?S9{6Ut; § 5.2.2 Subject to other provisions of the Design -Build Documents, the amount of each progress payment shall be computed as follows: .1 Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the Contract Sum allocated to that portion of the Work in the schedule of values, less retainage of percent( %) on the Work, other than services provided by design professionals and other consultants retained directly by the Design -Builder. Pending final determination of cost to the Owner of Changes in the Work, amounts not in dispute shall be included as provided in Section A.7.3.8 of Exhibit A, Terms and Conditions; .2 Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction (or, if approved in advance by the Owner, suitably stored offthe site at a location agreed upon in writing), less retainage of percent ( %); .3 Subtract the aggregate of previous payments made by the Owner; and .4 Subtract amounts, if any, for which the Owner has withheld payment from or nullified an Application for Payment as provided in Section A.9.5 of Exhibit A, Terms and Conditions. § 5.2.3 The progress payment amount determined in accordance with Section 5.2.2 shall be further modified under the following circumstances: .1 add, upon Substantial Completion of the Work, a sum sufficient to increase the total payments to the full amount ofthe Contract Sum, less such amounts as the Owner shall determine for incomplete Work, retainage applicable to such work and unsettled claims; and (Section X4.9.8.6 of Exhibit .4, Terms and Conditions requires release of applicable retainage upon Substantial Completion of Work with consent ofsurety, if arty.) .2 add, if final completion of the Work is thereafter materially delayed through no fault of the Design -Builder, any additional amounts payable in accordance with Section A.9.10.3 of Exhibit A, Terms and Conditions. § 5.2.4 Reduction or limitation of retainage, if any, under Section 5.2.2 shall be as follows: (YU is intended, prior to Substantial Completion of the entire Work, to reduce or limit the retainage resultin g gfromthe Percentages inserted in Sections 5.2.2.1 and 5.2.2.2 above, and this is not explained elsewhere in the Design -Build -- Documents, insert here provisions for such reduction or limitation.) § 5,3 PROGRESS PAYMENTS • COST OF THE WORK PLUS A FEE § 5.3.1 Where the Contract Sum is based upon the Cost of the Work plus a fee without a Guaranteed Maximum Price, Applications for Payment shall show the Cost of the Work actually incurred by the Design -Builder through the end of the period covered by the Application for Payment and for which Design -Builder has made or intends to make actual payment prior to the next Application for Payment. § 5.3.2 Subject to other provisions of the Design -Build Documents, the amount of each progress payment shall be computed as follows: .1 Take the Cost of the Work as described in Exhibit B; .2 Add the Design -Builder's Fee, less retainage of percent( %). The Design -Builder's Fee shall be computed upon the Cost of the Work described in the preceding Section 5.3.2.1 at the rate stated in Section 4.3.2; or if the Design -Builder's Fee is stated as a fixed sum in that section, an amount which bears the same ratio to that fixed -sum Fee as the Cost of the Work in the preceding section bears to a reasonable estimate of the probable Cost of the Work upon its completion; .3 Subtract the aggregate of previous payments made by the Owner; .4 Subtract the shortfall, if any, indicated by the Design -Builder in the dOCUfnentation required by Section 5.1.4 or resulting from errors subsequently discovered by the Owner's accountants in such documentation; and .5 Subtract amounts, if any, for which the Owner has withheld or withdrawn a Certificate for Payment as provided in the Section A.9.5 of Exhibit A, Terms and Conditions. 5.3.3 Retainage in addition to the retainage stated at Section 5.3.2.2, if any, shall be as follows: '��..., Init t . 3a::.. a r!t �1+t -;iG: L'cpyrignt t120t)A ay me lar•-=3n;.2n!n$ld: Le of !veli;tecta. Adl d5h).5 iE}:tiit'Jar7, riA-t`iR(G Th;S .:,tA.• •, , , .:''. ^ :t'.: l..'.. ...t .n ;a:. �n�:_fIa i!• , , .. 1 - : Gnlsh:4 se•.. ;>crv,l an•'�'rirdn.1 .., .._ .iC,.,•.P....l.i::.. �r :...�:D, .. _,,l G•a:;�' ,..;r, •.. r.• .i .t .. _ ,.. ... ,. Urn t!tiasr'alid will be pr.-,4ec uted�(o Uter.um ext• ll( possib-N under the N-,' This !Velum nN w.Rstp!nouced by AIA t'r..(1•naie Ft 13 1 % 41 an 0612 5; 20,12 under O(der No 0278369107 1 wNch-acires :.)n1 U%t6(2012 and is ncr for re -&Ie User _. (t Ot?758 -8U 5 } ..-�..,,I _k:M k.... dm „• ..n,,.. �,., , ,,-, .... -I -- ,,. ., ...:. r..111-11111 _.1.111. 1.- . — ___ �L 1 § 5.3,4 Except with the Owner's prior approval, payments for the Work, other than for services provided by design Professionals and other consultants ietalned directly by the Design-13uilder,.shall be subject to retainage of not less than Percent( %). The Owner and Design;Btfildeir shall agree on a mutually acceptable procedure for review and approval of payments and retention for Contractors. § 5.4 PROGRESS PAYMENTS - COST OF THE WORK PLUS A FEE WITH A GUARANTEED MAXIMUM PRICE § 5.4.1 Applications for Payment where the Contract Sum is based upon the Cost of the Work Plus a Fee with a pe cove Maximum Pitice sh4ll'show the percentage of completion of each portion of the Work as of the end of the period covered b. the Application for Payment, The percentage of completion shall be the lesser of (1) the percentage of that portiort of the Wot`k:which has actually been completed; or (2) the percentage obtained by dividing (a) the expense that has actually beth incurred by the.Desigrt-Builder on account ofthat portion of the Work for which the Design -Builder has made or iittOlds to make actual payment prior to the next Application for Payment by (b) the share of the Guaranteed Maximum Price allocated to that portion of the Work in the schedule of values. § 5.4.2 Subject to other provisions of the Design -Build Documents, the amount ofeach progress payment shall be computed as follows: .1 Take that portion of the Guaranteed Maximum Price properly allocable to completed Work as determined by multiplying the percentage of completion of each portion ofthe Work by the share of the Guaranteed Maximum price allocated to that portion of the Work in the schedule of values. Pending final determination of cost to the Owner of changes in the Work, amounts not in dispute shall be included as provided in Section A.73.8 of Exhibit A, Terms and Conditions; •2 Add that portion of the Guaranteed Maximum Price properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the Work, or if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing; .3 Add the Design -Builder's Fee, less retainage of percent ( %). The Design -Builder's Fee shall be computed upon the Cost of the Work described in the two preceding sections at the rate stated in Section 4,4.2 or, ifthe Design -Builder's Fee is stated as a fixed sum in that section, shall be an amount that bears the same ratio to that fixed -sum fee as the Cost of the Wok in the two preceding sections bears to a reasonable estimate of the probable Cost of the Work upon its completion; .4 Subtract the aggregate of previous payments made by the Owner; .5 Subtract the shortfall, if any, indicated by the Design -Builder in the documentation required by Section 5.1.4 to substantiate prior Applications for Payment, or resulting from errors subsequently discovered by the Owner's accountants in such documentation; and .6 Subtract amounts, if any, for which the Owner has withheld or nullified a Certificate for Payment as provided in Section A.9.5 of Exhibit A, Terms and Conditions. § 5.4.3 Except with the Owner's prior approval, payments for tate Work, other than for services provided by design professionals and other consultants retained directly by the Design -Builder, shall be subject to retainage of not less than percent( %), The Owner and Design -Builder shall agree on a inutuaIly acceptable procedure for review and approval of payments and retention for Contractors. § 5.5 FINAL PAYMENT § 5.5.1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Design -Builder no later than 30 days after the Design -Builder has fully performed the Design -Build Contract, including the requirements in Section A.9.10 of Exhibit A, Terms and Conditions, except for the Design -Builder's responsibility to correct non -conforming Work discovered after final payment or to satisfy other requirements, if any, which extend beyond final payment. ARTICLE 6 DISPUTE RESOLUTION § 6.1 The parties appoint the following individual to serve as a Neutral pursuant to Section A.4.2 of Exhibit A, Terms and Conditions: (Insert the name, address and other infor»urtion of the inclividual to serve as a Neutral. ff the parties do not select a Nerltral, then the provisions of Section A. 4.2.2 of Exhibit A, Terms and Conditions, .shall apply.) _ , ,. --- ^te rz A s Init r�t..t.,ivu:. r 1-.{Atlt.Ccpyriui-rt a OC•ti, ,. na;; _ _ __ _ __ --- .-...__._.- -----�---•----- t: ani; rn!:.:r•s .. _ _ Fnstaart[ .. _ It*_l . ,AII YLih� mse. —1. WARtaIhEC• . ^r5 %-.1r' aocu.n2n it gale -tad by v'hr• R �a� - ap•: iu - i :,( !h;L. .�!.`. 7J•'+Lii illd ��. i.. ori ,:u, Ji',1.: ::Su,r sc. er ri:•it and c:�mi?a1 Janalt!es. a' J r7fl be WIMF.CLIted to the rnax:rnum xtert possible under the lav; This dorkanefV was ypr ,duced byAl.A softwvafe at t 13 17:41 ori 01i/2512')1,. under Order No 527f;369107 I which expires Ori 1 Qr 16120 1 2, and IS not t0( resale (User !dotes: ! 1097884M) 161 If the parties do not tesdlve thein dispute through mediation pursuant to Section A.4.3 of Exhibit A, Terms and Conditions; the method ofbinding dispute resolution shall be the following: (!f thepgrties do rot select u methed fifbihding dispute .resolution, then the method of binding dispute resolution shall be by litigallon in a court of oompetentiurisdictiort) (Check one.) [ X ] Arbitration pursuant to Section A.4.4 of Exhibit A, Terms and Conditions [ ] Litigation in a court of competent jurisdiction [ ] Other (Spec) § 6.3 ARBITRATION § 6.3.1 [f Arbitration is,sclectedby thc.parties as the method of binding dispute resolution, then any claim, dispute or other ><rtatfer in question attjng:oui"ofdr related to this Agreement shall be subject to arbitration as provided in Section A.4.4 of gxhibit A,'Terms and Conditions,. ARTICLE 7 MISCELLANEOUS PROVISIONS § 7.1 The Architect, other design professionals and cbnsultants engaged by the,Design-Builder shall be persons or entities duly licensed to practice their professions in the judisdidd where tho liroject is located and are listed as follows: (Insert name, address, license number, relationship to Design -Builder and other information) Name and Address License Number Relationship to Other Information Design -Builder § 7.2 Consultants, if any, engaged directly by the Owner, their professions and responsibilities are listed below: (Insert name, address, license number, if applicable, and responsibilities to Owner and other information.) Name and Address License Number Responsibilities Other information to Owner § 7.3 Separate contractors, if any, engaged directly by the Owner, their trades and responsibilities are listed below: (Insert name, address, license number, if"applicable, responsibilities to Owner and other information.) Name and Address License Number Responsibilities Other Information to Owner 7.4 The Qwner's Designiatt-A t?.^rr1'4ser!tat!v is: (Insert Weans, crddrer,., and oiher irj )rn-woon.) Jeff Peden.+,: City urP;!ducah Proico Manager P 0. Bu.; 22f:i Paducah, KY 4200 Init A1A bocumcri A1•;1+ -. 2.004. Wapyrid+t! Jj?+1!i.t >y'7.y.; 4„!Gr, dr:!r.32rlut5 a1.'tircn+ICCts. A11 si n1a rs!tlra o . OtAPMP4w Plis A!h` [ •;c�r!16ut Nro;.;:tt!: ,; \`y,.,.•.- !J 5 CCu; rlgl±' i_::w ar; r! :r+?,r%?I!tx. ! i '.!a Fln •r_t:::ris c.<? : .,.+:alio:. ;;r diSvit;v.�,irt�u? :n P; A!A:'`' rvevare ctyll Ind c nrnasl p2na!l123, and as 11 bE Proyeculod to itlermur.!mu!n extunt PQ. Me uncle: thhaw l'fres document was produced hyAIA sofnxare at / 13:17:41 on 06/2S/2012 under Order No 5276369107 1 which e xp!rr s on 10/16/2012, and is net far resaie Use; Notes - (1097684601% ,� , s h . .., ,.I I , ... .. _ 1 § 7.4.1 The Owner's Designated Representative identified above shall be authorized to act on the Owner's behalf with respect to the Project. § 7,5 The Design -Builder's Designated Representative is: (Insert name, address and other information.) Biu Boyd A&K Construction, Inc. 100 Calloway Court Paducah, KY 42001 § 7.5.1 The Design -Builder's Designated Representative identified above shall be authorized to act on the Design -Builder's behalf with respect to the Project. § 7.6 Neither the Owner's nor the Design -Builder's Designated Representative shall be changed without ten days written notice to the other party, § 7.7 Other provisions: § 7,7.1 Where reference is made in this Agreement to a provision of another Design -Build Document, the reference refers to that provision as amended or supplemented by other provisions of the Design -Build Documents. § 7.7.2 Payments due and unpaid under the Design -Build Contract shall bear interest from the date payment is due at the rate stated below, or in the absence thereof, at the legal rate prevailing from time to time at the place where the Project is located. (Insert rate of interest agreed upon if any.) percent ( %) (Usury laws and requirements under the Federal Truth in Lending Act, similar state and local consumer credit laws and other regulations ctt the Owners a andel,4end Design- 811ilder .s principal places of business, the location of the Project whe►e tn{y' affect the validity ofthis provision. Legal advice shoulelbe obtained with respect to deletions or modifications, and also regarding requirements such as written dsclosures or waivers.} ARTICLE 8 ENUMERATION OF THE DESIGN -BUILD DOCUMENTS § 8.1 The Design -Build Documents, except for Modifications issued after execution of this Agreement, are enumerated as follows: § 8.1.1 Tile Agreement is this executed edition of the Standard Form of Agreement Between Owner and Design -Builder, AIA Document A141-2004. § 8.1.2 The Supplementary and other Conditions of the Agreement, if any, are as follows: (Either list applicable documents below or refer to an exhibit attached to thisAgreement. Document Title Pages § 8.1.3 The Project Criteria, including changes to the Projcct Criteria proposed by the Design -Builder, if any, and accepted by the Owner, consist of the following: (Either list applicable documents and their dates below or refer to an exhibit attached to this Agreement.) AIAUCUmG,nt A.fdi v PY 91111 12004 by he Amr:;call 1,:Mi n, trsil c L7 ,° 2ULI' o r :'lu; a' Archri2ets. Ail rigWla reserver!. Nd.M<N!'••!i;• v;rs qI A.' !);,r,umene Ib prul� U °r`/`fight t.a'r' a::e Intcr<: +Ctcr. arlm,gl Tre2f;us Una:ai,artr.,.;i :¢�ru.u:c::o:car l)Or.,!ITlnli, ;7r 1.^.., ;;Or,�arr cf i:, est g nti't.rp CiV ti incl Ciir,ari 9f (}Cit arriri?. artA Will 'l:? Dio3c!r C1:i.S La fi,g dlslnuuli::n 3r DOS AlA 13.17.4 1 on 08/25/2012 urde; Order No .2,,,,,,.7I which axpires an 1,01W201?, and is not fm resale I:e,', n,. 4xu:rseni 1ye1s Fswvucsd y AIA cltv.a,r: a; usar Notes - (10()7684601) Title Date § 8.1.4 The Design -Builder's Proposal, dated , consists of the following: (Either list applicable documents below or refer to an exhibit attached to this Agreement.) § 8.1.5 Amendments to the Design -Builder's Proposal, if any, are as follows: (Either list applicable documents below or refer to an exhibit attached to this Agreement.) § 8.1.6 The Addenda, if any, are as follows: (Either list applicable documents below or refer to an exhibit attached to this Agreement.) Number Date Pages § &V Exhibit A, Terms and Conditions. (If the parties agree to substitute terms and conditions other than those contained in AIA Document A141-2004, Exhibit A, Terms and Conditions, then idento such terms and conditions and attach to this Agreement as Exhibit A) § 8.1.8 Exhibit B, Determination of the Cost of the Work, if applicable. (If the parties agree to substitute a method to determine the cost of the Work other than that contained in AIA Document.4141-2004, Exhibit B, Determination of the Cost of the Work then idents such other method to determine the cost of the Work and attach to this Agreement as Exhibit B. If the Contract .Sum is a Stipulated Sum, then Exhibit B is not applicable.) § 8.1.9 Exhibit C, Insurance and Bonds, if applicable. (Complete AIA Document A141-2004, Exhibit C, Insurance and Bonds or indicate 'not applicable.'] § 8.1.10 Other documents, if any, forming part of the Design -Build Documents are as follows: (Either list applicable documents below or refer to an exhibit attached to this Agreement.) This Agreement entered into as of the day and year first written above. DESIGN -BUILDER (Signature) (Printed name and title) (Printed name and title) OWNER (Signature) (Printed name and title) Init. AIA Document At41 TM —2004 Oooyrigh! t'i 2004 by TIlr, Aniatiew in8!iW,,e of ArchileGts. All rlgbts mserved. Mi< IING^ Thl•; Xj)A' CY.;sume:ni ia, tarolactad +!y a .5 copyn'gt-o ;.me a:la Iw am stir r.,a; ;; g1f :5 t r as+li.atez.er! reffr.%+7..:cYic n nr Y+isfri'ru{ic,n of this AAA` [t,ratatrert. Orta>iy pr.rnor Of It. m01,- .rsetit u. 5fjV,wrn .ctrit r+nq cri,-ntncal ponaft+er.., aml w±lf be ;n:;llia. uted :O the ina.xlrnun •_x!::aS possthle unt5er Ww im,. This uor.ument was produced by AIAsoftwarr_ a: 10 t 13 17:41 on 06/25/2012 under Order No 5276369107_1 which expires on 10/16/2012, and is not for resale User Notes: (1097684601) AMENDMENT TO THE STANDARD FORM OF AGREEMENT BETWEEN OWNER AND DESIGN -BUILDER AIA A141-2004 ARTICLE 1 THE DESIGN -BUILD DOCUMENTS 1.1 Add the following to document to the list of documents that constitute the Design -Build Documents: "RFP # 2013-01 CALL CENTER DESIGN BUILD SERVICES". ARTICLE 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 3.1 Revise subparagraph to read: "The date of commencement of the Work shall be the date of this Agreement." 3.2 Add paragraphs 3.2.1 and 3.2.2 as follows: "3.2.1 Liquidated Damages for Delay in Substantial Completion: Design -Builder shall pay Owner the sum of Two Thousand and 000/100 Dollars ($2,000.00) per day for each and every calendar day of delay in achieving Substantial Completion beyond 260 days from the date of this Agreement (the "Substantial Completion Date"). Any sums due and payable hereunder by Design -Builder shall be payable, not as a penalty, but as liquidated damages representing an estimate of delay damages likely to be sustained by Owner. Such liquidated damages shall apply regardless of whether Design -Builder has been terminated by Owner prior to Substantial Completion so long as Design -Builder's actions or inactions contributed to the delay. Such liquidated damages shall be in addition to and not in preclusion of the recovery of actual damages resulting from other defects in Design -Builder's performance hereunder for matters other than delays in Substantial Completion. When Owner reasonably believes that Substantial Completion will be inexcusably delayed, Owner shall be entitled, but not required, to withhold from any amounts otherwise due to Design -Builder an amount then believed by Owner to be adequate to recover liquidated damages applicable to such delays. If and when Design -Builder overcomes the delay in achieving Substantial Completion, or any part thereof, for which Owner has withheld payment, Owner shall promptly release to Design -Builder those funds withheld, but no longer applicable as liquidated damages." "3.2.2 Liquidated Damages for Delay in Final Completion: If Design -Builder fails to achieve Final Completion on or 276 days from the date of this Agreement (the "Final Completion"), the Design - Builder shall pay Owner Two Thousand and 00/100 Dollars ($2,000.00) per day for each and every calendar day of unexcused delay in achieving Final Completion beyond the date established for Final Completion of the Work. Any sums due and payable hereunder by Design -Builder shall be payable, not as a penalty, but as liquidated damages representing an estimate of delay damages likely to be sustained by Owner. Such liquidated damages shall apply regardless of whether Design -Builder has been terminated by Owner prior to Substantial Completion so long as Design -Builder's actions or inactions contributed to the delay. Such liquidated damages shall be in addition to and not in preclusion of the recovery of actual damages resulting from other defects in Design -Builder's performance hereunder for matters other than delays in Substantial Completion. When Owner reasonably believes that Substantial Completion will be inexcusably delayed, Owner shall be entitled, but not required, to withhold from any amounts otherwise due to Design -Builder an amount then believed by Owner to be adequate to recover liquidated damages applicable to such delays. If and when Design -Builder overcomes the delay in achieving Substantial Completion, or any part thereof, for which Owner has withheld payment, Owner shall promptly release to Design -Builder those funds withheld, but no longer applicable as liquidated damages." Page 1 of 3 ARTICLE 4 CONTRACT SUM 4.2 STIPULATED SUM — Delete the entire section. 4.3 COST OF THE WORK PLUS DESIGN -BUILDER'S FEE — Delete the entire section. 4.4.1 Revise the subparagraph to read: "The Cost of the Work is as defined in Exhibit B, which includes the Design -Builder's Fee and .is subject to the Guaranteed Maximum Price as set forth in Section 4.4.3.1." ARTICLE 5 PAYMENTS 5.2 PROGRESS PAYMENTS — STIPULATED SUM — Delete entire section. 5.3 PROGRESS PAYMENTS — COST OF THE WORK PLUS A. FEE — Delete entire section. 5.4 Add paragraph 5.4.4, as follows: "5.4.4 Reduction or limitation of retainage shall be as follows: The Owner shall retain ten percent (10%) from each Application for Payment up to fifty percent (50%) completion of Work, then, provided the Work is on schedule and satisfactory, and upon written request of the Design -Builder together with consent of surety, the Owner shall approve a reduction in retainage to five percent (51%) of the current Contract Sum. No part of the five percent (5%) retainage shall be paid until after Substantial Completion of the Work, as defined in the General Conditions of the Contract for Construction. After Substantial Completion, a reduction to a lump sum amount less than five percent (5%) retainage may be approved by the Owner when deemed reasonable. The minimum lump sum retainage shall be twice the estimated cost to correct deficient or incomplete work." 5.5.1 Add as condition to final payment the following: "the Design -Builder provides the Owner with affidavits that all payrolls, bills for materials, supplies and equipment, and other indebtedness connected with Work have been paid or otherwise satisfied, and with Consent of Surety for final payment." ARTICLE 7 MISCELLANEOUS .PROVISIONS 7.7.2 Delete entire section. ARTICLE 8 ENUMERATION OF THE DESIGN -BUILD DOCUMENTS 8.1.3 Add the following Project Criteria: "Title TELETECH BASE TECHNICAL REQUIREMENTS - RFP # 2013-01 8.1.4 Revise the sentence to read: "The Design -Builder's Proposal, dated March 4, 2013, as revised per Addendum #5 dated March 26, 2013, to RFP # 2013-01 and re -submitted on April 3, 2013, by Design - Builder consists of the following: Title Date Scope of Work March 4, 2013 Scope of Work (revised) April 3, 2013 Page 2 of 3 • � .i , b �I , I . � . ... _�_�� i ice_ � �_� � __ — �, — �, _ i 1��,1 � _� 8.1.5 Revise the sentence to read: "Amendments to the Design -Builder's Proposal, if any, are as follows: Title Date Scope of Work (revised) June 25, 2013 Value Engineering Items 6-25-13 Schematic Floor Plan — New Facility for Teletech 6-14-13 END OF AMENDMENT Page 3 of 3 t� VAIA Document A141" - 2004 Exhibit A Terms and Conditions for the following PROJECT: (Name and location or address) Teletech Call Center 2301 McCracken Boulevard Paducah, KY 42001 THE OWNER: (Name and location) City of Paducah & County of McCracken County THE DESIGN -BUILDER: (Name and location) A&K Construction, Inc 100 Calloway Court Paducah, KY 42001 TABLE OF ARTICLES A.1 GENERAL PROVISIONS A.2 OWNER A.3 DESIGN -BUILDER AA DISPUTE RESOLUTION A.5 AWARD OF CONTRACTS AX CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS A.7 CHANGES IN THE WORK A.8 TIME A.9 PAYMENTS AND COMPLETION A.10 PROTECTION OF PERSONS AND PROPERTY A.11 INSURANCE AND BONDS AA2 UNCOVERING AND CORRECTION OF WORK A.13 MISCELLANEOUS PROVISIONS A.14 TERMINATION OR SUSPENSION OF THE DESIGN -BUILD CONTRACT ADDITIONS AND DELETIONS: The author of this document has added Information needed for Ks completion. The author may also have revised the text of the original AIA standard form. An Additions and Detedons Report that notes added Information as well as revisions to the standard form text is available from the author and should be reviewed. A vertical One In the left margin of this document indicates where the author has added necessary Information and where the author has added to or deleted from the original AIA text. This document has important legal consequences. Consultation with an attorney is encouraged with respect to Its completion or modification. Consultation with an attorney is also encouraged with respect to professional licensing requirements in the jurisdiction where the Project is located. AIA DocumanY A1141 tr" _ 20"04" -Exhibit A. Copyright (t' 2004 Dy i'ne American Inslitutc of Architects. All rights reserved. 'N.s.krdP:(, I h: ; AI,;" -' Document is protected try U.S. Copyright Law and 1n?ernatio7nel rreatla Unauthorire;t reproduction or disir!bu!ion or this AIA" Document. of any Portion of i1,'nay re-sult in severe civil and crirnina) pananies, and will be prosecuted to the maximum extent possible under the taw. Thisdocumenl 1 was produced by AIA soft -,a e of 11:07:40 on W0712006under O dei rd�.1000170112 t which a>.pires on 3124/2008, and; not for resale. user NWes' (210179300) ARTICLE A.1 GENERAL PROVISIONS § A.1_1 BASIC DEFINITIONS § A.1.1.1 THE DESIGN -BUILD DOCUMENTS The Design -Build Documents are identified in Section I - I of the Agreement. § A.1.1.2 PROJECT CRITERIA The Project Criteria are identified in Section 8.1.3 of the Agreement and may describe the character, scope, relationships, forms, size and appearance of the Project, materials and systems and, in general, their quality levels, Performance standards, requirements or criteria, and major equipment layouts. § A-1.1.3 ARCHITECT The Architect is the person lawfully licensed to practice architecture or an entity lawfully practicing architecture identified as such in the Agreement and having a direct contract with the Design -Builder to perform design services for all or a portion cif the Work, and is referred to throughout the Design -Build Documents as if singular in number. The term "Architect" means the Architect or the Atchirect•s authorized representative. § A.1.1,4 CONTRACTOR A Contractor is a person or entity, other than the Architect, that has a direct contract with the Design -Builder to perform all or a portion of the construction required in connection with the Work. The term "Contractor" is referred to throughout the DEs-hm Build Dacumcnts as if singular in 10101ber'tind means a Contractor or an authorized representative of the !Cvntt�tcfor, The term ""Contractor" does:not.itt0lude. aseparate Contractor,. as defined in Section A.6.1.2, or subcontractors of a separate contractor. § A.1,1.5 SUBCONTRACTOR A Subcontractor is a person or entity who has a direct contract with a Contractor to perform a portion of the construction required in connection with the Work at the site. The term "Subcontractor" is referred to throughout the Design -Build Documents as if singular in number and means a Subcontractor or an authorized representative of the Subcontractor. § A.1.1.8 THE WORK The term "Work" means the design, construction and services required by the Design -Build Documents, whether completed or partially completed, and includes all other labor, materials, equipment and services provided or to be provided by the Design -Builder to fulfill the Design -Builder's obligations, The Work may constitute the whole or a part of the Project. § A.1.1,7 THE PROJECT The Project is the total design and construction of which the Work performed under the Design -Build Documents may be the whole or a part, and which may include design and construction by the Owner or by separate contractors, § A.1,1.8 NEUTRAL ' The Neutral is the individual appointed by the parties to decide Claims and disputes pursuant to Section A.4.2.1. § A,1.2 COMPLIANCE WITH APPLICABLE LAWS § A-1.2.1 If the Design -Builder believes that implementation of any instruction received from the Owner would cause a violation of any applicable law, statute, ordinance, building code, rule or regulation, the Design -Builder shall notify the Owner in writing. Neither the Design -Builder nor any Contractor or Architect shall be obligated to perform any act which they believe will violate any applicable law, ordinance, rule or regulation, A,i,2.2 Tltc Desi fir.-fiuikJcr shall ht cntitle(1 ro rvly r)it Ihr completeness and accuracy of the information contained in tile: Project Criteria. bu(not that sten Infornta horl compli.-s with applicable laws, regulations and codes, which shall be the obligation (if the Design 13uiklcr to determine. In the event that a specific requirement of the Project Criteria conflicts with applicable laws, regulations and codes, the Design -Builder shall furnish Work which complies with such laws, regulations and codes. In such case, the Owner shall issue a Change Order to the Design - Builder unless the Design -Builder recognized such non-compliance prior to execution or this Agreement and Failed to notify the Owner. AIA ................ ;ocument A141M-2004 Exhlbit A. Copyright @?_004 by The American Institute of Architects. All rights reserved. WARNIhIG. This AIA' — Document is protjesuli ecied by Se U S. Clapyrighl Lain• -4nd International Treaties Unaulhorized reproduction or distribritcon of thin AIA'Dacumer.:, or ar" parWBSron of it, ilrQdtJCerJ h?,11.1. 50�1�,,3fu ,ere civil and umninal Panatlles, and will be prosecuted to the nlBXimurr` sxlenl possible• ur',der the lay... This dca!meni / ` at 11:07.40 on �;. ,) r?2U06 under Order No.10001'l0 f 12 ; which axpires nn 3@?l�OOf, and is not for resats. User Notes: ('� 10179:100) § A.1.3 CAPITALIZATION § A.1.3,1 Terms capitalized in these Terms and Conditions include those which are (1) specifically defined, (2) the titles of numbered articles and identified references to sections in the document, or (3) the titles of other documents published by the American Institute of Architects. § A.1.4 INTERPRETATION § A.1.4.1 In the interest of brevity, the Design -Build Documents frequently omit modifying words such as "all" and "any" and articles such as "the" and "an," but the fact that a modifier or an article is absent from one statement and appears in another is not intended to affect the interpretation of either statement. § A-1.4.2 Unless otherwise stated in the Design -Build Documents, words which have well-known technical or construction industry meanings are used in the Design -Build Documents in accordance with such recognized meanings. § A.1,5 EXECUTION OF THE DESIGN -BUILD DOCUMENTS § A,1.5.1 The Design -Build Documents shall be signed by the Owner and Design -Builder. § A.1.5.2 Execution of the Design -Build Contract by the Design -Builder is a representation that the Design -Builder has visited the site, become generally familiar with local conditions under which the Work is to be performed and correlated personal observations with requirements of the Design -Build Documents. § A.1,6 OWNERSHIP AND USE OF DOCUMENTS AND ELECTRONIC DATA § A,1.6.1 Drawings, specifications, and other documents including those in electronic form, prepared by the Architect and furnished by the Design -Builder are Instruments of Service. The Design -Builder, Design -Builder's Architect and other providers of professional services individually shall retain all common law, statutory and other reserved rights, including copyright in those instruments of Services furnished by them. Drawings, specifications, and other documents and materials and electronic data are furnished for use solely with respect to this Project. § A.1.6.2 Upon execution of the Design -Build Contract, the Design -Builder grants to the Owner a non-exclusive license to reproduce and use the Instruments of Service solely in connection with the Project, including the Project's further development by the Owner and others retainedby the Owner for such purposes, provided that the Owner shall comply with all obligations, including prorflpt payment of sums when due, under the Design -Build Documents. Subject to the Owner's •eompllance with such obligations, such license shall extend to those parties retained by the 'Owner for such purposes, including other design professionals. The Design -Builder shall obtain similar non- exclusive licenses from its design professionals, including; the Architect, The Owner shall not otherwise assign or transfer any license herein to another party without prior written agreement of the Design -Builder. Any unauthorized reproduction or use of the Instruments of Service by the Owner or others shall be at the Owner's sole risk and expense without liability to the Design -Builder and its design professionals. Except as provided in Section A.1.6.4, termination of this Agreement prior to completion of the Design -Builder's services to be performed under this Agreement shall terminate this license. § A.1.6.3 Prior to any electronic exchange by the parties of the Instruments of Service or any other documents or materials to be provided by one party to the other, the Owner and the Design -Builder shall agree in writing on the specific conditions governing the format thereof, including any special limitations or licenses not otherwise provided in the Design -Build Documents. § A.1.6.4 If this Agreement is terminated for any reason other than the default of the Owner, each of the Design - Builder's design professionals, including the Architect, shall be contractually required to convey to the Owner a non-exclusive license to use that design professional's Instruments of Service for the completion, use and maintenance of the Project, conditioned upon the Owner's written notice to that design professional of the Owner's assumption of the Design -Builder's contractual duties and obligations to that design professional and payment to that design professional of all amounts dui to tint d :;ic:, professional and its consultants. If the Owner does not assume the remaining duties and obligation!; of the Design-f3uilde.r to that design professional under this Agreement, then the Owner shall indemnify and brild hanilfoss that design ptofcssional from all claims and any expense, including legal fees, which that design professional shall thereafter incur by reason of the Owner's use of such .Instruments of Service. The Design -Builder shall incorporate the requirements of this Section A.1.6.4 in all agreements with its design professionals. ---ed. - ------- A f..>ocument.AlAi TM-2Wa Exhibit A. Copyright � 20i1d by The :%�erican Institute of Architects. All rights resrr)e�. 4�ARFf1i•1G Ttv AIA' -- f.To: i.rrnerd L5 ;Molar -ted by tt 8 t;o rigfrf Lay. PY anri In•.<_:na��n:.at 7reaii:,s UnaWhen<ed : r:;�:�rtior, o: di.;!;ib:,l;en ; ,..• ton i!(:.u:•-::. i. •,; 4Y'8 :)rk ll^,E', Yp Pi-oult in, 3oVc' (;''Jig 3:Ir% Cri1TIIn3r ;renalli� .?. and wdl Ob r;- seculad io file alaximurn extent pl.." , lot%:,uruiCr ;li= ow'"r is dJcumc!il Q r F aar;wi:ra st l tO7:AQ nn Uis'�',:Pr �r� untie• Ltrtfer Nn.70Gi11-i0' :2 'I v; nie;h expires r.�:.7:'l4/2GOE';.:.inr's rGi for •esyiy .,i,. .Hrti. - .� .,. ., L, § A.1.6.5 Submission or distribution of the Design -Builder's documents to meet official regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in derogation of the rights reserved in Section A.1.6.1. ARTICLE A.2 OWNER § A.2.1 GENERAL § A.2.1,1 The Owner is the person or entity identified as such in the Agreement and is referred to throughout the Design -Build Documents as if singular in number. The term "Owner" means the Owner or the Owner's authorized representative; The Owner shall designate iii writing a representative who shall have express authority to bind the Owner with respect to all Project matters requiring the Owner's approval or•authorzation. The0►vner shall render decisions in a timely manner and in. accordance with the .DesignBuiider's schedule submitted to the Owner. § A.2.1.2 The Owner shall furnish to the Design -Builder within 15 days after receipt of a written request information necessary and relevant for the Design -Builder to evaluate, give notice of or enforce mechanic's lien rights. Such information shall include a correct statement of the record legal title to the property on which the Project is located, usually referred to as the site, and the Owner's interest therein. § A.2.2 INFORMATION AND SERVICES REQUIRED OF THE OWNER § A.2.2A infprnfation:.or:wxvig4* togtuied of the Owner by the Design -Build Documents shall be furnished by the Owne< with reasonably pro nlptness. Apy..g.ther information or services relevant to the Design -Builder's performance tsf the Wor%uttdar lite Owner's control Shall be furnished by the Owner after receipt from the Design -Builder of a written request for such information or services, § A,2.2,2 The Ownec:ahaU be respOnsible,to.plrovide.surveys, if not required by the Design -Build Documents to be provided by the Deslgn_$�)�j� dese;Ibitsg pKysical cltiracteristics, legal limitations, and utility locations for the site of tW$?-# jac4.and.a � nhen.tegal dt~sMpt on�ofthie site. The surveys and legal information shall include, as applicaBle, gtaites $lid: lines;of:streets� t+Iieys, pevetneWs. and adjoining property and structures; adjacent drainage; .ngttfs'of` Y. r a ves; :easemgnts,.encioachtiiet.0i ming, deed restriction, boundaries, and contours of the site; locations; dintensioaseand necessary data ppettaiiiiitg to exisiittg buitd[ngs;.osher iiiipsovetnents and trees; and iiiforraation concerning aI. .....ilie utility services and lines, both public and private; abtave acid below grade, including inverts and •depths, All the information on the sutvey-shall be ref6renced to a ftoject benchmark. § A.2.2.3 The Owner shall provide, to the extent available to the Owner and if not required by the Design -Build Documents to be provided by the Design -Builder, the results and reports of prior tests, inspections or investigations conducted for the Project involving structural or mechanical systems, chemical, air and water pollution, hazardous materials or environmental and subsurface conditions and information regarding the presence of pollutants at the Project site. § A,2.2.4 The Owner may obtain independent review of the Design -Builder's design, construction and other documents by a separate architect, engineer, and contractor or cost estimator under contract to or employed by the Owner. Such independent review shall be undertaken at the Owner's expense in a timely manner and shall not delay the orderly progress of the Work. § A.2.2.5 The Owner shall cooperate with the Design -Builder in sCruring building and other per►ni.ts, licenses and inspections. The Owner shall not be required to pay the fees fur such perniits. linens: s and inspections unless the cost of such fees is excluded from the responsibility nt'tile Design -Builder under the Dc:si,;tl-l3uilcl Documents. § A.2.2.5 The servit rs, inforrriatiml, sort-cys and reports required to be providCd 11, 1110 t.lv:r r urxi< ,tit cti. tt A.2.2, ,:hall be furnished ai the Owner's exllens and the Design -Builder shall be etuitlec: to rely upon ih;_ aCCUMuq and uoillpletelh:$s ,hereto, except as otherwise specifically provided in the Design-;tiild Docnmew; or to the extent the the I esi 7fl-Builder to the c:ontrary in writing. § A.2.2.7 If the Owner observes or otherwise becomes aware of a fault or defect in the Work or non -conformity with the Design -Build Documents, the Owner shall give prompt written notice thereof to the Design -Builder. lit Oosunlmenl e.11r;ent is A 941 TM — 2004 Exhiblt A. Copyright 02004 by The American Institute of Architects. All rights reserved. WARNING: This Alit` protected by U.S. Copyrigh! t_aw internavon3! Tr.>.ntr� , UngttthoriZed reproducrion or distribution., of this AIA' n:;••�rne:,o p!::�!c•n or it, may result sav®re civ;, and crlmi t was producer, y i71a penaaiss, antl svia be prosecuted to the rnaximuin extent possible under the taw 11115 documenl y AIA sidtware at 11:07:40 nn 02/0712006 under Order No- 10001701112 1 which expires oa 3/24/20,06. and is not for r �ssalc. i.r,eridote&: (2i0; 930o) § A-2,2.8 The Owner shall, at the request of the Design -Builder, prior to execution of the Design -Build Contract and promptly upon request thereafter, furnish to the Design -Builder reasonable evidence that financial arrangements have been made to fulfill the Owner's obligations under the Design -Build Documents. § A.2.2.9 The Owner shall communicate through the Design -Builder with persons or entities employed or retained by the Design -Builder, unless otherwise directed by the Design -Builder. § A,2.2.10 The Owner shall furnish the services of geoteclutical engineers or other consultants, if not required by the Design -Build. Documents to be.proxided by the Des€gh-Builder, for subsoil. air and water conditions when such services are deemed reasonably necessary by the Design -Builder to properly carry out the design services provided by the' Design Builder and the Design -Builder's Architect. Such services may include, but are not limited to, test boringsi test p€% determinations of soil bearing values, percolation tests, evaluations of hazardous materials, ground corrosion and.resistivity tests, and necessary operations for anticipating subsoil conditions. The services of geotechnical engineer(s) or other consultants shall include preparation and submission of all appropriate reports and professional recommendations. § A-2.2.11 The Owner shall promptly obtain easements, zoning variances, and legal authorizations regarding site utilization where essential to the execution of the Owner's program. § A.2.3 OWNER REVIEW AND INSPECTION § A,2.3.1 The Owner.ahall review -and approve or take 6.1her appropriate action upon the Design -Builder's submittals, including but:tiot ter! to design attid `construction docurni ntsi. required by die Design -Build Documents, but only fol'.the titnited purpose of checking forconfortrtattee Wath infortuation giVoh-and the design concept expressed in the Design -Build Documents. The Owner's action shall be taken with such reasonable promptness as to cause no delay in the Work or in the activities of the Design -Builder or separate contractors. Review of such submittals is not conducted for the purpose of determining the accuracy and completeness of other details, such as dimensions and quantities, or for substantiating instructions for installation or performance of equipment or systems, all of which remain the responsibility of the Design -Builder as required by the Design -Build Documents. § A.2.3.2 Upon review of the design documents, construction documents, or other submittals required by the Design- - - Build Documents, the Owner shall take one of the following actions: .1 Determine that the documents or submittals are in conformance with the Design -Build Documents and approve them. .2 Determine that the documents or submittals are in conformance with the Design -Build Documents but request changes in the documents or submittals which shall be implemented by a Change in the Work. .3 Determine that the documents or submittals are not in conformity with the Design -Build Documents and reject them. .4 Determine that the documents or submittals are not in conformity with the Design -Build Documents, but accept them by implementing a Change in the Work, .5 Determine that the documents or submittals are not in conformity with the Design -Build Documents, but accept them and request changes in the documents or submittals which shall be implemented by a Change in the Work, § A.2.3.3 The Design -Builder shall submit to the Owner for the Owner's approval, pursuant to Section A.2.3.1, any proposed change or deviation to previously approved documents or submittals. The Owner shall review each proposed change. or deviation to previously approved documents or submittals which the Design -Builder submits to the ()v: net for the: Owiii:r's approval with reasonable promptness in accordance with Section A.2.3.1 and shall make 01- cif the deter minatinn:i described in Section A.2.3.2. § A.2.3.4 Notwithstanding the Owner's responsibility under Section A.2.3.2, the Owner's review and approval of the Design -Builder's documents or submittals shall not relieve the Design -Builder of responsibility for compliance with the Design -Build Documents unless a) the Design -Builder has notified the Owner in writing of the deviation prior to approval by the Owner or, b) the Owner has approved a Change in the Work reflecting any deviations from the. requirements of the Design -Build Documents, A!A Document A141 .,. — 2004 Ubibill A. Copyright 0_0 2004 by "rhe American Institute cd Architects. Ali rights reserver -i. 1vARtL'N:,: This A!A ` — nAiaamrrd i rAtected. h�f r U S r.:npyriyhi l.n_w anti ;1Ji1�rn:3ti•^, ?! 7fc81:r;: rJnJU!hAl::ed :2=fAiUGtip^ Or dcarit,:<ti, n ,,.' !iris A!k" Cr c;irn2::;. cr %o, perr cr:iof it, MAY resui! :n Sei5"re r;!vu ana crimin'M fen liaa and will be prosecwftj tb liie Il7xir0uf•i e=i l:1 i LS. !e undt;r thy, !w, fids dricurwai. avas ,;reduced by AIA softwsre at ! 1.07AC on tit/ M006 ,••r!e: Or]rr No.10001 %;1 l" 1 which s z ires Corr :i.2.1; .'' c Usf,r .,user;. = F ') . o,!d's not for fesakj. t£'.r!r 795i --7,1,111-1-611-11-1. , , ,,. _. , ..., '----. _ _. __ __. ..._ a _. ,:_J § A.2,3.5 The Owner may visit the site to keep informed about the progress and quality of the portion of the Work completed. However, the Owner shall not be required 'to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. Visits by the Owner shall not be construed to create an obligation on the part of the Owner to make on-site inspections to check the quantity or quality of the Work. The Owner shall neither have eonorol over or charge of; nor be responsible for, the construction means, methods, techniques, sequences or procedures, or for the safety precautions -and pragratm in co Design -Builder's righnnection with the Work, since these are solely the ts and responsibilities gilder the Design -Build Documents, except as provided in Section A,3,3,7. § A.2,3.6 The Owner shall not be responsible for the Design -Builder's failure to perform the Work in accordance with the requirements of the Design -Build Documents. The Owner shall not have control over or charge of and will not be responsible for acts or omissions of the Design -Builder, Architect, Contractors, or their agents or employees, or any other persons or entities performing portions of the Work for the Design -Builder. § A.2.3.7 The Owner may reject Work that does not conform to the Design -Build Documents. Whenever the Owner considers it necessary or advisable, the Owner shall have authority to require inspection or testing of the Work in accordance with Section A.13,5.2, whether or not such Work is fabricated, installed or completed. However, neither this authority of the Owner nor a decision made in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Owner to the Design -Builder, the Architect, Contractors, material and equipment suppliers, their agents or employees, or other persons or entities performing portions of the Work. § A.2.3.6 The Owner may appoint an on-site project representative to observe the Work and to have such other responsibilities as the Owner and the Design -Builder agree to in writing. § A,2.3,9 The Owner shall conduct inspections to determine the date or dates of Substantial Completion and the date of final completion. § A,2.4 OWNER'S RIGHT TO STOP WORK § A.2.4.1 If the Design -Builder fails to correct Work which is not in accordance with the requirements of the Design - Build Documents as required by Section A. 12.2 or persistently fails to carry out Work in accordance with the Design -Build Documents, the Owner may issue a written order to the DesigwBuitder to stop the Work, or any Portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Design -Builder or any other person or entity, except to the extent required by Section A.6.13. § A.2.5 OWNER'S RIGHT TO CARRY OUT THE WORK § A.2.5.1 If the Design -Builder defaults or neglects to carry out the Work in accordiincc with the Design -Build Documents and fails within a seven-day period afler receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may after such seven-day period give the Design -Builder a second written notice to correct such deficiencies within it three-day period. If the Desi;n-Builder within such three-day period after receipt of such second notice fails to commence and continue to correct any deficiencies, the Owner may, without preitidice to other remedies the Owner may have, correct such deficiencies, its such case, an approlht-iatc Change Order shall be issued deducting from payments then or thereafter due the Design -Builder the reasonable cost of correcting such deficiencies. If payments due the Design -Builder are not suflicient to carver such amounts, Lite Msign-Duildc:r shall pay the difference to the Owner. ARTICLE A.3 DESIGN -BUILDER § A,3.1 GENERAL § A,3.1.1 The Design -Builder is the person or entityirle:lti _ iii tl•a :� ;rrcut.lti mid' is r�4erred to throughout the Design -Build Documents as if singular in number. The D si4gn Builderrtay hr an architco or other- design professional, a construction contractor, a real estate developer or any other pe*rsoll or entity )egsally permitted to do busiticrss as a design-huilder m the locatinn -these the Project is located. The term "Design -Builder" means the I),^sign-Builder or theDesign-Builder`s .:uthcsrizecl representative. The Design -Builder's representative is authorized t4 area rttt tine 1)e::il r1-Iiuilder'� behalf• %visit re:;pecl to the Project. § A,3.1.2 The Design -Builder shall perform the Work in accordance with the Design -Build Documents. AIA Document A141 to -_.----•-----------__.._ . 2004 Exhibit A. Cgpyriyitt Q 2004 by The American Institute of Architects. All rights reserved. WARNING: This AIA' Document is protected by U S. Copyright Law and International Treaties Unauthorized reproduction or distribution of this AIA' Duc!tment, or any portion n1 it, may resell in sevetr_ civil and crintined penalties, and will be prosecuted to the maximum extent possible under the law. This docurnenl C was produced by AIA software .1, 11.07:40 00 021071200%, under Order No.1000170112. (which expires or, 3,''24J200o, and is not for reside. Use; Notes: (210179300) § A.3.2 DESIGN SERVICES AND RESPONSIBILITIES y § A.3.2.1 When applicable law requires that services be performed by licensed professionals, the Design -Builder shall provide those services through the performance of qualified persons orettttties duly liicensed to practice their profeltsibihs. The -Owner understands and agrees that the services performed by the Design -Builder's Architect and the Design -Builder's other design professionals and consultants are undertaken and performed in the sole interest of and for the exclusive benefit of the Design -Builder. § A.3.2.2 The agreements between the Design Builder and Architect or other design professionals identified in the Agreement, and in any subsequent Modifications, shall be in writing. These agreements, including services and financial arrangements with respect to this Project, shall be promptly and fully disclosed to the Owner upon the Owner's written request. § A.3.2.3 The Design -Builder shall be responsible to the Owner for acts and omissions of the Design -Builder's employees, Architect, Contractors, Subcontractors and their agents and employees, and other persons or entities, including the Architect and other design professionals, performing any portion of the Design -Builder's obligations under the Design -Build Documents. § A.3.2A The Design -Builder shall carefully study and compare the Design -Build Documents, materials and other information provided by the Owner pursuant to Section A.2.2, shall take field measurements of any existing conditions related to the Work, shall observe any conditions at the site affecting the Work, and report promptly to the Owner any errors, inconsistencies or omissions discovered. § A.3.2.5 The Design Builder shall provide to the Owner for Owner's written approval design documents sufficient to establish the size, quality and character of the Project; its architectural, structural, mechanical and electrical systems; and the materials and such other elements of the Project to the extent required by the Design -Build Documents. Deviations, if any, from the Design -Build Documents shall be disclosed in writing. § A.3.2.8 Upon the Owner's written approval of the design documents submitted by the Design -Builder, the Design - Builder shall provide construction documents for review and written approval by the Owner. The construction documents shall set forth in detail .the requirements for coitstiuction of'the -Project. The construction documents shall include drawings and specifications that establish the quality levels of materials and systems required. Deviations, if any, from the Design -Build Documents shall be disclosed in writing. Construction documents may include drawings, specifications, and other documents and electronic data setting forth in detail the requirements for construction of the Work, and shall: .1 be consistent with the approved design documents; .2 provide information for the use of those in the building trades; and .3 include documents customarily required for regulatory agency approvals. § A.3.2.7 The Design -Builder shall meet with the Owner periodically to review progress of the design and construction documents. § A.3.2.8 Upon the Owner's written approval of construction documents, the Design -Builder, with the assistance of the Owner, shall prepare and file documents required to obtain necessary approvals of governmental authorities having jurisdiction over the Project. § A.3.2.9 The Design -Builder shall obtain from each of the Design -Builder's professionals and furnish to the Owner certifications with respect to the documents and services provided by such professionals (a) that, to the best of their knowledge, information and belief, the documents or services to which such certifications relate (i) are consistent with the Project Criteria set forth in the Design -Build Documents, except to the extent specifically identified in such certificate, (ii) comply with applicable professional practice standards, and (iii) comply with applicable laws, ordinances, codes, rules and regulations governing the design of the Project; and (b) that the Owner and its consultants shall be entitled to rely upon the accuracy of the representations and statements contained in such certifications. § A.3.2.10 If the Owner requests the Design -Builder, the Architect or the Design -Builder's other design professionals to execute certificates other than those required by Section A.3.2.9, the proposed language of such certificates shall be submitted to the Design -Builder, or the Architect and such design professionals through the Design -Builder, for Al ocument A141 TM - 2.004 Exhibit A. G ri t © 2004 b The American Institute of Architect_. 8PY 9h Y All rights reserved. WARNING This AIA,' Document is prute.^trd oy U. . copy,41( Law rind In?a:nc!i;v,a! Treaties Unauthorized reprod;.ction or dismbunon of this, AIA' Jo: ur,:,.ru, u+ an•, porter. -of it. may result in se•+ere cie,t ar:d ;rim;na! penalties, and will be pro.^.^>ecuied it) the maxnrum--axtenj oos^!bte under the !aw INS documer. was produced by AIA sof1w3:e at t t :0?:;r a:; 02101f2l:,; Lmcrer orr,'nr vo.10001?01 12 '1 which r:xpi:, s on 3;24'2006. and is not for resale User metes: review and negotiation at Ieast 14 days prior to the requested dates of execution. Neither the Design -Builder, the Architect nor such other design professionals shall be required to execute certificates that would require knowledge, services or responsibilities beyond the scope of their respective agreements with the Owner or Design -Builder. § A.3.3 CONSTRUCTION § A.3.3.1 The Design -Builder shall perform no construction Work prior to the Owner's review and approval of the construction documents. The Design -Builder shall perform no portion of the Work for which the Design -Build Documents require the Owner's review of submittals, such as Shop Drawings, Product Data and Samples, until the Owner has approved each submittal. § A.3.3.2 The construction Work shall be in accordance with approved submittals, except that the Design -Builder shall not be relieved of responsibility for deviations from requirements of the Design -Build Documents by the Owner's approval of design and construction documents or other submittals such as Shop Drawings, Product Data, Samples or other submittals unless the Design -Builder has specifically informed the Owner in writing of such deviation at the time of submittal and (1) the Owner has given written approval to the spec deviation as a minor change in the Work, or (2) a Change Order or Construction Change Directive has been issued authorizing the deviation. The Design -Builder shall not be relieved of responsibility for errors or omissions in design and construction documents or other submittals such as Shop Drawings, Product Data, Samples or other submittals by the Owner's approval thereof. § A.313 The Design -Builder shall direct specific attention, in writing or on resubmitted design and construction documents or other submittals such as Shop Drawings, Product Data, Samples or similar submittals, to revisions other than those requested by the Owner on previous submittals. In the absence of such written notice, the Owner's approval of a resubmission shall not apply to such revisions, § A.3.3.4 When the Design -Build Documents require that a Contractor provide professional design services or certifications related to systems, materials or equipment, or when the Design -Builder in its discretion provides such design services or certifications through a Contractor, the Design -Builder shall cause professional design services or certifications to be provided by a properly licdhsed design professional, whose signature and seal shall appear on all drawings, calculations, specifications, dertificaCions, Shop 13rawliings and other submittals prepared,by such professional. Shop Drawings and other submittals related to the Work designed or certified by such professionals, if Prepared by others, shall bear such design professional's written approval. The Owner shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals. § A.3.3.5 The Design -Builder shall be solely responsible for and have control over all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Design -Build Documents. § A.3.3.8 The Design -Builder shall keep the Owner informed of the progress and quality of the Work. § A.3.3.7 The Design -Builder shall be responsible for the supervision and direction of the Work, using the Design - Builder's best skill and attention. If the Design -Build Documents give specific instructions concerning construction means, methods, techniques, sequences or procedures, the Design -Builder shaII evaluate the jobsite safety thereof and, except as stated below, shall be fully and solely responsible for the jobsite safety of such means, methods, techniques, sequences or procedures. If the Design -Builder determines that such means, methods, techniques, sequences or procedures may not be safe, the Design -Builder shall give timely written notice to the Owner and shall not proceed with that portion of the Work without further written instructions from the Owner. If the Design -Builder is then instructed to proceed with the required means, methods, techniques, sequences or procedures without acceptance of changes proposed by the Design -Builder, the Owner shall be solely responsible for any resulting loss or damage. § A.3.3.8 The Dest'gn-Builder shall be responsible for inspection of portions of Work already perforated to determine that such portions are in proper condition to receive subsequent Work. Alp: [tocurrtant A141ne -2004 Exhibit A. Copyright 02004 ny Thi American Instiiute o(Archifects. All rights reseived. WARratt#r; This Ate.' Un::utner,t is protected ny !1 - c �'opyr�;;1;t.3,rer;dlntems-a: al;realr.: Jnautho:iz.ed:, r po li n of it, may rrsu;r �p odusr:;n ar dr nriG�tun C•I t;:•& ; ;,' In re ;err i _and urrr,mal rena!nc•s. •ar•,r? rrh Lt� ros2cr„eo to �hc n,arirrun�.�r.!e.it po„it:,ic ur.der�ti� , 1*w tiai;; •1,;c�;rre::' b t^:ata prprluCe.: wy AIA :cr,!ywari- -_ 11:07 3'r r•, fir, r : F N • c• .' 6 %:?Gti': ,;n^er .t, • i•ln. t yr;fit 701 12 1 wnich expires ; ) - - - ares ^r. •312: '. i Ou. d,:c( �.: r,..1 ire ....... § A.3.4 LABOR AND MATERIALS A.3.4.1 Unless otherwise provided in the Design -Build Documents, the Design -Builder shall provide or cause to be provided and shall pay for design services, labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation and other facilities and services necessary for proper execution and completion of the Work, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work. § A.3A.2 When a material is specified in the Design -Build Documents, the Design -Builder may make substitutions only with the consent of the Owner and, if appropriate, in accordance with a Change Order. § A.3.4.3 The Design -Builder shall enforce strict discipline and good order among the Design -Builder's employees and other persons carrying out the Design -Build Contract. The Design -Builder shall not permit employment of unfit Persons or persons not skilled in tasks assigned to them. § A.3.5 WARRANTY § A.3.5.1 The Design -Builder warrants to the Owner that materials and equipment furnished under the Design -Build Documents will be of good quality and new unless otherwise required or permitted by the Design -Build Documents, that the Work will be free from defects not inherent in the quality required or permitted by law or otherwise, and that the Work will coliform to the requirements of the Design -Build 1)ueutnenls. Wgrk not confgrmutg to these cegtiirctr+ents, Including substitutions. not properly approved. anti authorized, may be considered defective. The Design-8tiil¢gr"s WMAhty excludes i`dmiidy fo>G daiiiage or.defect caused by abuse; modifiesiions not executed by the' De igti Bttltcler; itnprapei oc insufficient maintenance, improper operation, or normal wear and tear and normal usage. If required by the Owner, the Design -Builder shall furnish satisfactory evidence as to the kind and quality of materials and equipment. § A.3.6 TAXES § A.3.6.1 The Design Builder shall pay all sales, consumer, use and similar taxes for the Work provided by the Design Builder which had been legally enacted on the date of the Agreement, whether or not yet effective or merely scheduled to go into effect. § AM PERMITS, FEES AND NOTICES § A-3.7.1 The Design -Builder shall secure and pay for building and other permits and governmental fees, licenses and inspections necessary for the proper execution 4nd..completion of'the Work which are customarily secured after execution of the Design -Build Contract and which were legally required on the date the Owner accepted the Design - Builder's proposal. § A.3.7,2 The Design -Builder shall comply with and give notices required by laws, ordinances, rules, regulations and lawful orders of public authorities relating to the Project. § A.3.7.3 It is the Design -Builder's responsibility to ascertain that the Work is in accordance with applicable laws, ordinances, codes, rules and regulations. § A,3.7.4 If the Design -Builder performs Work contrary to applicable laws, ordinances, codes, rules and regulations, the Design -Builder shall assume responsibility for such Work and shall bear the costs attributable to correction. § A.3.8 ALLOWANCES § A.3.8.1 The Design -Builder shall include in the Contract Sum all allowances stated in the Design -Build Documents. Items ck�veret! by alh:wlur,:c : shall be supplied for such amounts and by such persons or entities as the Owner may direct, but ttla lir ;i n 13!lill; r shall not be required to employ persons or entities; to which the Desutr! Builder has reasonable (illlek-D 11 § A.3.8.2 Unless otherwise provided in the Design -Build Documents: .1 allowances shall cover the cost to the Design -Builder of materials and equipment delivered at the site and all required taxes, less applicable trade discounts; .2 Design -Builder's costs for unloading and handling at the site, labor, installation costs, overhead, profit and other expenses contemplated for stated allowance atnounts shall be included in the Contract Sum but not in the allowances;'and Alli rpp "!'I Ei:t ft141 T'n - 2084 Exhibit A. Gopyrlyht «J 2004 'o;i T:ie Anarican Inslitutc� of A;chitoris. All ri0ttts r::ser•yed. 'tllttiNlNr� This Ala `1o;;!, r.73n� ,r r,: q12^(,•�:' t:;y U..:i ;lar_;, i,,ht �;,v; ruts! lnt�rna[icr tz! 'rr,-.,exit:a Ua,+n>t arit Frc r,7 �n�:dui.-"c .., ar dr_:tobuuoi o1'hr "IA' Guoun:,:,:;. ibn of a'u:ey ra-,-u.1 in :;., �e� _ cr iii art r r. r7; Ural ;+cr•�hie>. an, v1M be n�osrr. �.:! ::! !r, I::r, mrixi:,i;rr• ,Misr, nossibk uc6er !h� r:. ii i, was produced by AIA eaiNvare at 1 1:0 i:40 on 02/07/2006 under Order No.1000170112__1 User Motes: which expires an 3r24/2006, and is not for resale (210179300) .3 whenever costs are more than or less than allowances, the Contract Sum shall be adjusted accordingly by Change Order. The amount of the Change Order shall reflect (1) the difference between actual costs and the allowances under Section A.3.8.2.1 and (2) changes in Design -Builder's costs under Section A.3.8.2,2. § A-3,8.3 Materials and equipment under an allowance shall be selected by the Owner in sufficient time to avoid delay in the Work. § A.3.9 DESIGN -BUILDER'S SCHEDULE § A,3.9,1 The Design -Builder, promptly after execution of the Design -Build Contract, shall prepare and submit for the Owner's information the Design -Builder's schedule for the Work, The schedule shall not exceed time limits and shall be in such detail as required under the Design Build Documents, shall be revised at appropriate intervals as required by the conditions of the Work and Project, shall be related to the entire Project to the extent required by the Design -Build Documents, shall provide for expeditious and practicable execution of the Work and shall include allowances for periods Of time required for the Owner's review and for approval of submissions by authorities having..jurisdiction over the Projeol. § A.19.2 The Design -Builder shall prepare and keep current a schedule of submittals required by the Design Build Documents. § A.3,9,3 The Design -Builder shall perform the Work in general accordance with the most recent schedules submitted to the Owner. § A.3.10 DOCUMENTS AND SAMPLES AT THE SITE § A,3,10.1 The Design -Builder shall maintain at the site for the Owner one record copy of the drawings, specifications, addenda, Change Orders and other Modifications, in good order and marked currently to record field changes and selections made during construction, and one record copy of approved Shop Drawings, Product Data, Samples and similar required submittals. These shall be delivered to the Owner upon completion of the Work. § A.3.11 SHOP DRAWINGS, PRODUCT DATA AND SAMPLES § A.3,11.1 Shop Drawings are drawings, diagrams, schedules and other data specially prepared for the Work by the Design Builder or a Contractor, Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. § A.3.11.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Design -Builder to illustrate materials or equipment for some portion of the Work. § A-3.11.3 Samples are physical examples that illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. § A,3.11.4 Shop Drawings, Product Data, Samples and similar submittals are not Design -Build Documents. The purpose of their submittal is to demonstrate for those portions of the Work for which submittals are required by the Design -Build Documents the way by which the Design -Builder proposes to conform to the Design -Build Documents. § A.3,11.$ The i-Dicsign-builder shall review for compliance with the Design -Build Documents and approve and subillit to III -c- Owner only th.)%(- Shnp Drawing;,, Pmdtwi I)ata, Samples and similar submittals required by the UcNi-n-Build Dtxnrlrmnts vdill reasnnahic prnrli;ane., ,roil in such sequence as to cause no delay in the Work or in they activities of thy. Owner or nf.serarntr: ,-omracwr.: § A.3.11.6 By approving and submitting Shop Drawings, Product Data, Samples and similar submittals, the Design - Builder represents that the Design -Builder has determined and verified materials, field measurements and field construction criteria related thereto, or will do so, and has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Design -Build Documents. --- -- --------- _ .. ,_ v— Doc mens is ntRc T"r - 20Uq Exhititt A, Capyrlght 2004 by The American Institute of Architects. All rights reserved. WARNING: This A,A� Document is prct�cted by U.S crpyrfohi t.aw and IntUrnatiLHldt Trw:rfia.[ UnauthoriMd reprodcction of di^,Inbtj4urr of this hl„ tl]Ct1m25. or an; 4lotnon or it, rna y result in >;evare civil and erirniital pei 111e i, and writ ae pnasecu'ed to the maximum eal2rt Fnssibtn. under The lar, This doccrmenl 10 was prcCucer; by A:A soNw2ra al 11:07:40 ,;n 02x0%7_006 undsr Qrder NO. 1000? TJ! 12 1 which expi,t:c on 3/7•;/20;6, snd ; nol kr r=sal=. Us r t+rat - IL 101 79(f00 r § A.3.12 USE OF SITE § A.3.12.1 The Design -Builder shall confine operations at the site to areas permitted by law, ordinances, permits and the Design -Build Documents, and shall not unreasonably encumber the site with materials or equipment. § A.3.13 CUTTING AND PATCHING § A.3.13.1 The Design -Builder shall be responsible for cutting, fitting or patching required to complete the Work or to make its parts fit together properly. § A.3.13.2 The Design -Builder shall not damage or endanger a portion of the Work or fully or partially completed construction of the Owner or separate contractors by cutting, patching or otherwise altering such construction or by excavation. The Design -Builder shall not cut or otherwise alter such construction by the Owner or a separate contractor except with written consent of the Owner and of such separate contractor, such consent shall not be unreasonably withheld. The Design -Builder shall not unreasonably withhold from the Owner or a separate contractor the Design -Builder's consent to cutting or otherwise altering the Work. § 4.3.14 CLEANING UP § A,3.t4:1 The Deslgn-Builder shall keep the premises apd surrounding area free from accutuulation of waste utaterials: or rubbisfi caused by operat otrs. under. 'the Design-Uld Contract. At completion of the Work, the Design - Builder shall remove fioin and about the Project waste materials, rubbish, the Design B.uilder's tools, construct on e'quipfMd tt, inabkiitecy and d ", Aus'tit&lariats, § A.3.14.2 If the Design -Builder fails to clean up as provided in the Design -Build Documents, the Owner may'do so and the cost thereof shall be charged to the Design -Builder. § A.3.15 ACCESS TO WORK § A.3.15.1 The Design -Builder shall provide the Owner access to the Work in preparation and progress wherever located. § A.3A6 ROYALTIES, PATENTS AND COPYRIGHTS § A.3,16.1 'the 06tigtl-Builder shall pay all royalties and license fees. The Design -Builder -shall defend suits or claims for ipfringetnetit of copyrights and patent rights and shall hold the Owner harmless from loss on account thereof, but shall not be responsible for such defense or loss when a particular design, process or product of a particular manufacturer or manufacturers is required or where the copyright violations are contained in drawings, specifica'd' ins or other documents prepared by or furnished to the Design -Builder by the Owner. However, if the Design -Builder has reason to believe that the required design, process or product is an infringement of a copyright or a patent, the Design -Builder shall be responsible for such loss unless such information is promptly furnished to the Owner. § A.3.17 INDEMNIFICATION § A.3.17.1 To the fullest extent permitted by law, the Design -Builder shall indemnify and hold harmless the Owner, Owner's consultants, and agents and employees of any of them from and against claims, damages, losses and expenses, including but not limited to attorneys' fees, arising out of or resulting from performance of the Work, provided that such claim, damage, loss or expense is attributable to bodily injury, sickness, disease or death or to injury to or destruction of tangible property other than the Work itself, but only to the extent caused by the negligent acts or omissions of the Design -Builder, Architect, a Contractor, a Subcontractor, anyone directly or indirectly employed by them or anyone for whose acts they may be liable, regardless of whether or not such claim, damage, loss or expense is caused in part by a party indemnified hereunder. Such obligation shall not be construed to negate, abridge or reduce other rights or obligations of indemnity that would otherwise exist as to a party or person described in this Section x,..3.17. § A.3.17.2 In claims against any person or entity indemnified under this Section A.3.17 by an employee of the Design -Builder, the Architect, a Contractor, a Subcontractor, anyone directly or indirectly employed by them or anyone for whose acts they may be liable, the indemnification obligation under Section A.3.17.1 shall not be limited by a limitation on amount or type of damages, compensation or benefits payable by or for the Design -Builder, the Architect or a Contractor or a Subcontractor under workers' compensation acts, disability benefit acts or other employee benefit acts. AIA nocurnent Al, 41'?m - 2004 Exhibit A. Copyright (0 2004 by "!'hc. Arnarnan Instit-Aa of A,chilects. A!1 lights reserved. WARNING, This Ai A' __.---�-�- C)•✓r.lria'•r" prnt.i•.;>d by li y:. Gb Ciy rig hl I..a V, a, id 1",, rr. i.::• T:r�!i::c iln:i:A r: p.i[Fd r:,J7rJti�. ., r. o• d•sirib,'i o:r r.? :nit: AIJ1� pnrrioit rt .: nc;y and rrirmcrr •r.e:.I 6.i31 ;A:1 fr.: prr,;,,r:uiad to tt:e rr.�x�tn..!nt extent p•a;;ii;6: •.i,•:Jcr iN,n l;.!�r Thie � cicurlao! Was are:;rv_'... iry �L': l? on _ , ...;]!0:?ii ..! v✓n;rh ^xpf�_ ut- - �i^.:A:?^!Jr:, :a•i i> .:ii 5...- �..o .. (2! c l 7J36 . ,.._.k, . 61111111 I, •n r :-I ---.1-1-11-111. 1-1 ...:. i . ......... .. .... ,. ... --...-1 ,. ___ ,, -- --d: ___ _.-.. ..-, �_1_ __ILA - ARTICLE AA DISPUTE RESOLUTION § AAA CLAIMS AND DISPUTES § A-4.1.1 Definition. A Claim is a demand or assertion by one of the parties seeking, as a matter of Eight, adjustment or interpretation of Design -Build Contract terms, payment of money, extension of time or other.relief with respect to the terms of the Design -Build Contract. The term "Claim" also includes other disputes. and matters in question between the Owner and Design -Builder arising out of or relating to the Design -Build Contract. Claims must be initiated by written notice. The responsibility to substantiate Claims shall rest with the party making the Claim. § A.4.1.2 Time Limits on Claims. Claims by either party must be initiated within 21 days after occurrence of the event giving rise to such Claim or within 21 days after the claimant first recognizes the condition giving rise to the Claim, whichever is later. Claims must be initiated by written notice to the other party. § AA.1,3 Continuing Performance. Pending final resolution of a Claim, except as otherwise agreed in writing or as provided in Section A.9.7.1 and Article A.14, the Design -Builder shall proceed diligently with performance of the Design -Build Contract and the Owner shall continue to make payments in accordance with the Design -Build Documents. § A,4.1.4 Claims for Concealed or Unknown Conditions, If conditions are encountered at the site which are (1) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Design - Build Documents or (2) unknown physical conditions of an unusual nature which differ materially from those or411401Y fotmi 10 exiiLand generaily recognized as.Wrent in construction activities of the character provided for in the Pesl'gn-Build Doc ime ts; then, the observingrt.. pashall give notice to the other party promptly before conditions *rc disturbed and in no evdnt later than 21 days after first observance of the conditions. The Owner shall Pruniptiy investigaie,such conditions: and, ft, they differ materially and cause an increase or decrease in the Design- Buili>[eYs.cost of; or Gate it tjuir f6r performance of any part of the Work, shall negotiate with the Design -Builder an equit4bWadjustment iit.ffi*Cottfraat Stem lir Contract Time, or both. If the Owner determines that the conditions at the site are not materially different From those indicated in the Design -Build Documents and that no change in the terms of the Design -Build Contract is justified, the Owner shall so notify the Design -Builder in writing, stating the reasons. Claims by the Design -Builder in opposition to such determination must be made within 21 days after the Owner has given notice of the decision. If the conditions encountered are materially different, the Contract Sum and Contract Time shall be equitably adjusted, but if the Owner and Design -Builder cannot agree on an adjustment in the Contract Sum or Contract Time, the adjustment shall proceed pursuant to Section A.4.2. § A-4.1.5 Claims for Additional Cost. If the Design -Builder wishes to make Claim for an increase in the Contract Sum, written -notice as provided herein shall be given before proceeding to execute the Work. Prior notice is not required for Claims relating to an emergency endangering life or property arising under Section A.10.6. § A.4.1.6 If the Design -Builder believes additional cost is involved for reasons including but not limited to (1) an order by the Owner to stop the Work where the Design -Builder was not at fault, (2) a written order for the Work issued by the Owner, (3) failure of payment by the Owner, (4) termination of the Design -Build Contract by the Owner, (5) Owner's suspension or (6) other reasonable grounds, Claim shall be filed in accordance with this Section AAA. § A.4.1,7 Claims for Additional Time § A.4.1.7.1 If the Design -Builder wishes to make Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Design -Builder's Claim shall include an estimate of the time and its effect on the progress of the Work. In the case of a continuing delay, only one Claim is necessary. § A,4.1.7,2 If adverse weather conditions are the basis for a Claim for additional time, such Claim shall be documented by data substantiating that weather conditions were abnormal for the period of time, could not have been reasonably anticipated and had an adverse effect on the scheduled construction. § A.4.1.8 Injury or Damage•to Person or Property. If either party to the Design -Build Contract suffers injury or damage to person or property because of an act or omission of the other party or of others for whose acts such party is legally responsible, written notice of'such injury or damage, whether or not insured, shall be given to the other party within a reasonable time not exceeding 21 days after discovery. The notice shall provide sufficient detail to enable the other Party to investigate the matter.• AIA Document A14ira-� .004 Exhibit A. Copyright G 2004 by The American Institute of Architects. All rights resarved. WARNING: This AIA` nxurnent is prolectecl by 1J s Copyright i.av: and 1 - f nh�nntlonal Treaties Urtau'nonze;t reprorJuclion or t)isir, i>uhar• 01 tfns AIA_ Or,cunt-;�: ;.r any �n1 portion of rt, n12v result m Stiles -r- `.Pill ar..y ; nminaf penalty,;,, anA :iu ba pruse,.u!ed to ih maximum ez!enl os[.ibie under 11;x; lax This rnCur,ieru vas pr(tcJirced by A',., sofis:aca 11:0 4Q y: 02/rl?/_008 urB2r Dnyer `;.;.1;1001701 12 1 'which expires on 3/24/20 J User Nctes: �' F, ono is nrrf icr n>;�6; .210?79300; `y § A.4.1.9 If unit prices are stated in the Design -Build Documents or subsequently agreed upon, and if quantities originally contemplated are materially changed in a proposed Change Order or Construction Change Directive so that application of such unit prices to quantities of Work proposed will cause substantial inequity to the Owner or Design -Builder, the applicable unit prices shall be equitably adjusted. § A.4.1,10 Claims for Consequential Damages. Design -Builder and Owner waive Claims against each other for consequential damages arising out of or relating to the Design -Build Contract. This mutual waiver includes: A damages incurred by the Owner for rental expenses, for losses of use, income, profit, financing, business and reputation, and for loss of management or employee productivity or of the services of such persons; and .2 damages incurred by the Design -Builder for principal office expenses including the compensation of Personnel stationed there, for losses of financing, business and reputation, and for loss of profit except anticipated profit arising, directly from the Work. This mutual waiver is applicable, without limitation, to all consequential damages due to either party's termination in accordance with Article A.14. Nothing contained in this Section A.4.1.10 shall be deemed to preclude an award of liquidated direct damages, when applicable, in accordance with the requirements of the Design -Build Documents. § A.4.1,11 If the enactment or revision of codes, laws or regulations or official interpretations which govern the Project causes an iu1..crew or decrease of the Design-Buildees dost of; or time required for, performance of the Work, elle l7esign=$uild¢r:ShFll .be entitled to 4aequitable adjustment in Contract Sum or Contract Time. If the Owner and Design44414er Cannot agft%4poit''an'AdjuStirtent in lhe':Conti~diet Suri or Contract Time, the Design Builder shall submit a Claim pursuant to Section A.4.1. § A.4.2 RESOLUTION OF CLAIMS AND DISPUTES § A.4.2,1 Decision by Neutral. If the parties have identified a Neutral in Section 6.1 of the Agreement or elsewhere in the Design -Build Documents, then Claims, excluding those arising under Sections A.10.3 through A.10.5, shall be referred initially to the Neutral for decision. An initial decision by the Neutral shall be required as a condition precedent to mediation of all Claims between the Owner and Design -Builder arising prior to the date final payment is due, unless 30 days have passed after the Claim has been referred to the Neutral with no decision having been rendered by the Neutral. Unless the Neutral and all affected parties agree, the Neutral will not decide disputes between the Design -Builder and persons or entities other than the Owner. § A.4.2.2 Decision by Owner. If the parties have not identified a Neutral in Section 6.1 of the Agreement or elsewhere in the Design -Build Documents then, except for those claims arising under Sections A.10.3 and A.10.5, the Owner shall provide an initial decision. An initial decision by the Owner shall be required as a condition precedent to mediation of all Claims between the Owner and Design -Builder arising prior to the date final payment is due, unless 30 days have passed after the Claim has been referred to the Owner with no decision having been rendered by the Owner. § A.4.2.3 The initial decision pursuant to Sections A.4.2.1 and A.4.2.2 shall be in writing, shall state the reasons therefore and shall notify the parties of any change in the Contract Sum or Contract Time or both. The initial decision shall be final and binding on the parties but subject first to mediation under Section A.4.3 and thereafter to such other dispute resolution methods as provided in Section 6.2 of the Agreement or elsewhere in the Design -Build Documents. § A.4.2.4 In the event of a Claim against the Design -Builder, the Owner may, but is not obligated to, notify the surety, if any, of the nature and amount of the Claim. If the Claim relates to a possibility of a Design -Builder',,, - default, the Owner- may, but is not obligated to, notify the surety and request the surety's assistance in resolving the controversy. § A.4.2.5 .If a Claim relates to or is the subject of a mechanic's lien, the party asserting such Claire may proceed in accordance with applicable law to comply with the lien notice or filing deadlines prior to initial resolution of the Claim. AtA Document A141 rAr - 2004 Exhibit A. Copyright I ht t� 7 2004 by The American institute of Architects. All rights reserved. WARNING This AIA` oocuawj::! is }ir ::kcteQ by U.S. copy•ighl t. `, �,i;d In'er nwior:,a 'f.es!f• Ihiau;iru: free reprodu%l,ort or d;$Cicu!ruri of ;his A!A^ U:;cl; ro=:rrt, ei an, p,rtian n. ii, i::ay result �n sr.i„xa crvfl :u« 1 enrnfi-.3 peri;,lliea..:,nd :rill be pmser.•rl,d to ih^c nia<iiw,m r,•xtanl possibie undo)! th:, lair This'locm,ment 13 was produced by A!A _oft,,we -,, f ! 07 rj : 0.?/0 ii<'..o6 w:`iOr. ,'e 1!g01 fi 112 -1 r+ir.;h ar iire, nn 3124!_006 nd i .:�tUserfr!eaS. § AA.3 MEDIATION § A.4.3.1 Any Claim arising out of or related to the Design -Build Contract, except those waived as provided for in Sections AAA -10, A.9.10.4 and A.9.10.5, shall, after initial decision of the Claim or 30 days after submission of the Claim for initial decision, be subject to mediation as a condition precedent to arbitration or the institution of legal or equitable or other binding dispute resolution proceedings by either party. § A.4,3.2 The parties shall endeavor to resolve their Claims by mediation which, unless the parties mutually agree otherwise, shall be in accordance with the Construction Industry Mediation Rules of the American Arbitration Association currently in effect at the time of the mediation. Request for mediation shall be filed in writing with the other party to the Design Build Contract and with the American Arbitration Association. The request may be made concurrently with the filing of a demand for arbitration or other binding dispute resolution proceedings but, in such event, mediation shall proceed in advance thereof or of legal or equitable proceedings, which shall be stayed pending mediation for a period of 60 days from the date of filing, unless stayed for a longer period by agreement of the parties or court order. § A-4.3.3 The parties shall share the mediator's fee and any filing fees equally. The mediation shall be held in the Place where the Project is located, unless another location is mutually agreed upon. Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof. § AM ARBITRATION § A.4,4.1 Claims, except those waived as provided for in Sections A.4,1,10, A.9.10.4 and A.9.10.5, for which initial decisions have not become final and binding, and which have not been resolved by mediation but which are subject to arbitration pursuant to Sections 6.2 and 6.3 of the Agreement or elsewhere in the Design -Build Documents, shall be decided by arbitration which, unless the parties mutually agree otherwise, shall be in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association currently in effect at the time of the arbitration. The demand for arbitration shall be filed in writing with the other party to the Design -Build Contract and with the American Arbitration Association. § A.4.4.2 A demand for arbitration may be made no earlier than concurrently with the filing of a request for mediation, but in no event shall it be made after the date when institution of legal or equitable proceedings based on such Claim would be barred by the applicable statute of limitations as determined pursuant to Section A.13.6. § A-4.4.3 An arbitration pursuant to this Section AAA may be joined with an arbitration involving common issues of law or fact between the Owner or Design -Builder and any person or entity with whom the Owner or Design -Builder has a contractual obligation to arbitrate disputes which does not prohibit consolidation or joinder. No other arbitration arising out of or relating to the Design -Build Contract shall include, by consolidation, joinder or in any other manner, an additional person or entity not a party to the Design -Build Contract or not a party to an agreement with the Owner or Design -Builder, except by written consent containing a specific reference to the Design -Build Contract signed by the Owner and Design -Builder and any other person or entities sought to be joined. Consent to arbitration involving an additional person or entity shall not constitute consent to arbitration of any claim, dispute or other matter in question not described in the written consent or with a person or entity not named or described therein. The foregoing agreement to arbitrate and other agreements to arbitrate with an additional person or entity duly consented to by the parties to the Agreement shall be specifically enforceable in accordance with applicable law in any court having jurisdiction thereof, § AAAA Claims and Timely Assertion of Claims. The party filing a notice of demand for arbitration must assert in the demand all Claims then known to that party on which arbitration is permitted to be demanded_ § A.4.4,5 Judgment on Final Award. The award rendered by the arbitrator or arbitrators shall be filial, and jucigs7ent may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. ARTICLE A.5 AWARD OF CONTRACTS § A.5.1 Unless otherwise stated in the Design -Build Documents or the bidding or proposal requirements, the Design - Builder, as soon as practicable after award of the Resign -Build Contract, shall furnish in writing to the Owner the names of additional persons or entities not originally included in the Design -Builder's proposal or in substitution of a person or entity (including those who are to furnish design services or materials or equipment fabricated to a special design) proposed for each principal portion of the Work. The Owner will promptly reply to the Design- _A1 esign- AIA ,r)a,curnerQ A14_1,_t14_ — Zp04 Exbibii A, Copyright Q 2004 hy; me 4rT B(ICBrt Institute of Arr:hitacts. 111 rig?its resarve-d. tV rA:�NkdG 1't is P.Ir, Dourn=.n1 i.., r riar•IFtl Ly l. .:,. Copyright Lan at'ut lnternat,or•al I;,a an urtauthorzaa reps;dueiren or drslr ibution at this AW Dctw.;rnen! o, any a cnrimn of it. may re.,ult in severe rivd ar!d rrirrnnat j,enalhes. and will ha �ro;ec,.;ted to the rnaxirnimi ,"!n;it poss't ie r der the law This dos.;r lr . n nSr[ aers pn d!,ced by A4; SC:f!wj17e ;.t t 1:07 :.; ,in 02,77/200:6 im1,,r%rdr r p,10, 1056. 7011'? Use( N6T?S: 1 which^xflirrs on /2,t'+006 and r, nu! {nr r:_a, j210 i 7? (XV. Builder in writing stating whether or not the Owner has reasonable objection to any such proposed additional person or entity. Failure of the Owner to reply promptly shall constitute notice of no reasonable objection. § A,5.2 The Design -Builder shall not contract with a proposed person or entity to whom which the Owner has made reasonable and timely objection. The Design -Builder shall not be required to contract with anyone to whom the Design -Builder has made reasonable objection. § A.5.3 If the Owner has reasonable objection to a person or entity proposed by the Design -Builder, the Design - Builder shall propose another to whom the Owner has no reasonable objection. If the proposed but rejected additional person or entity was reasonably capable of performing the Work, the Contract Sum and Contract Time shall be increased or decreased by the difference, if any, occasioned by such change, and an appropriate Change Order shall be issued before commencement of the substitute person's or entity's Work. However, no increase in the Contract Sum or Contract Time shall be allowed for such change unless the Design -Builder has acted promptly and responsively in submitting names as required. § A.5.4 The Design -Builder shall not change a person or entity previously selected if the Owner makes reasonable objection to such substitute. § A.5.5 CONTINGENT ASSIGNMENT OF CONTRACTS § A.S.5.1 Each agreement for a portion of the Work is assigned by the Design -Builder to the Owner provided that: -1 assignment is effective only after termination of the Design -Build Contract by the Owner for cause Pursuant to Section A.14.2 and only for those agreements which the Owner accepts by notifying the contractor in writing; and .2 assignment is subject to the prior rights of the surety, if any, obligated under bond relating to the Design -Build Contract. § A.5.5.2 Upon such assignment, if the Work has been suspended for more than 30 days, the Contractor's compensation shall be equitably adjusted for increases in cost resulting from the suspension. ARTICLE A.6 CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS § A.6.1 OWNER'S RIGHT TO PERFORM CONSTRUCTION AND TO AWARD SEPARATE CONTRACTS § A.6.1,1 The Owner reserves the right to perform construction or operations related to the Project with the Owner's own forces and to award separate contracts in connection with other portions of the Project or other construction or operations on the site. The Design -Builder• shall cooperate with the Owner and separate contractors whose work might interfere with the Design -Builder's Work. If the Design -Builder claims that delay or additional cost is involved because of such action by the Owner, the Design -Builder shall make such Claim as provided in Section A.4.1. § A.6,1.2 The term "separate contractor" shall mean any contractor retained by the Owner pursuant to Section A. 6.1.1. § A.6.1.3 The Owner shall provide for coordination of the activities of the Owner's own forces and of each separate contractor with the work of the Design -Builder, who shall cooperate with them. The Design -Builder shall participate with other separate contractors and the Owner in reviewing their construction schedules when directed to do so. The Design -Builder shall make any revisions to the construction schedule deemed necessary after a joint review and mutual agreement. The construction schedules shall then constitute the schedules to be used by the Design -Builder, separate contractors and the Owner until subsequently revised. 3 A.6.2 MUTUAL RESPONSIBILITY § A.6.2.1 The Design -Builder shalt afford the Owner and separate contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities and shall connect and coordinate the Design -Builder's construction and operations with theirs as required by the Design -Build Documents. § A.6.2.2 If part of the Design -Builder's Work depends for proper execution or results upon design, construction or operations by the Owner or a separate contractor, the Design -Builder shall, prior to proceeding with that portion of the Work, promptly report to the Owner apparent discrepancies or defects in such other construction that would render it unsuitable for such proper execution and results. Failure of the Design -13 wilder so to report shall constitute AIA r10acumenl A141Iv— --)-•---------------- --- 00, x t I . t•opynght (°-200=4 by The American ins ,lute of Architects.. All rignig reserved. YdAAMNIG This AIA iiC'. Jfrlt r:i p - :.tc:' .ai•y !.. C:Jppnyli! isr ::nd fntrn[it•c:Un.J:;:i-� ;rizru {v_rJrcd::ctio•: or rrisinu.;l-:n-: o! ihiz..G.l:," Doa.{me•r: - pa�tior, cl r ;ViBV resW; ri' s!.u•_re ^ivif anti Cr:inwO pc-�!< 1 �•1 : `:• _ ! tJti l:J :+., ,tired !n':s r(.a-(an Ji:'' .; 1:!r!� rl :'.!t:1t: J�^,. •• i, lc !•1 Yr .•:s r' :20b5 {, Jd:, r NO !nr � l 12 Nn c. - of-•, r _ ---L'_ I_ _ . -L,_ ,,. --- ___A --- L — u — 4- -L an acknowledgment that the Owner's or separate contractor's completed or partially completed construction is fit and proper to receive the Design -Builder's Work, except as to defects not then reasonably discoverable. § A.6.2.3 The Owner shall be reimbursed by the Design -Builder for costs incurred by the Owner which are payable to a separate contractor because of delays, improperly timed activities or defective construction of the Design - Builder. The Owner shall be responsible to the Design -Builder for costs incurred b. the Design -Builder because of delays, improperly timed activities, damage to the Work or defective construction of a separate contractor. § A.6.2.4 The Design -Builder shall promptly remedy damage wrongfully caused by the Design -Builder to completed or partially completed construction or to property of the Owner or separate contractors. § A.6,2,5 The Owner and each separate contractor shall have the same responsibilities for cutting and patching as are described in Section A.3.13. § A,6.3 OWNER'S RIGHT TO CLEAN UP § A-6,3.1 If a dispute arises among the Design -Builder, separate contractors and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish, the Owner may clean up and the Owner shall allocate the cost among those responsible. ARTICLE A,7 CHANGES IN THE WORK § A,7.1 GENERAL § A.7.1.1 Changes in the Work may be accomplished after execution of the Design -Build Contract, and without invalidatii gthei Desigm-Build Contract, by Change Order or Construction Change Directive, subject to the limilatidns stated in this Article A.7 and elsewhere in the Design -Build Documents. § A.7.1.2 A Change Order shall be based upon agreement between the Owner and Design -Builder. A Construction Change Directive may be issued by the Owner with or without agreement by the Design -Builder. § A.7.1.3 Changes in the Work shall be performed under applicable provisions of the Design -Build Documents, and the Design -Builder shall proceed promptly, unless otherwise provided in the Change Order or Construction Change Directive. § A.7.2 CHANGE ORDERS § A.7.2.1 A Change Order is a written instrument signed by the Owner and Design -Builder stating their agreement upon all of the following: .1 a change in the Work; .2 the amount of the adjustment, if any, in the Cor>tract Sum; and .3 the extent of the adjustment, if any, in the Contract Time. § A.7.2.2 if the Owner requests a proposal for a change in the Work from the Design -Builder and subsequently elects not to proceed with the change, a Change Order shall be issued to reimburse the Design -Builder for any costs incurred for estimating services, design services or preparation of proposed revisions to the Design -Build Documents. § A.7.2.3 Methods used in determining adjustments to the Contract Sum may include those listed in Section A.7.3.3. § A.7.3 CONSTRUCTION CHANGE DIRECTIVES § A,7,3.1 A Construction Change Directive is a written order signed by the Owner directing a change in the Work prior to agreement on adjustment, if any, in the Contract Stun or Contract Time, or both. The Owner may by Construction Change Directive, without invalidating the Design -Build Contract, order changes in the Work within the general scope of the Design -Build Documents consisting of additions, deletions or other revisions, the Contract Sum and Contract Time being adjusted accordingly. § A•7.3,2 A Construction Change Directive shall, be used in the absence of total agreement on the terms of a Change Order. AIA pocument A141T^' _ y U. ECopy, A. Copyright ©2004 by Tha American Institute of Architects. AN rights reserved. WARtdii•tr3 This AAA`' Occun:rrn+ u; pr erected by U.S CopyNght Lav: and inlorn;Nlonni i reafles Unauthorized reproduction or dtslrr.bulien of nna AW -c or are, portion o! it, may result in snv�ry civil and oritninai penalties, and will be prosecuted to the mar.;murn extent possibler under th,t !aw Thi= documeol 96 we produced by AIA sofivrg;e al 1 1.97A0 on 02/071,?p06 Vnd j!, :girder No.t000170112 1 which expires an X2412006, and is no. for resale ,J.aar Notes: - (210171307; § A.7.3.3 If the Construction Change Directive provides for an adjustment to the Contract Sum, the adjustment shall y , be based on one of the following methods: .1 mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit evaluation; •2 unit prices stated in the Design -Build Documents or subsequently agreed upon, or equitably adjusted as provided in Section A.4,1.9; .3 cost to be- determined in a manner agreed upon by the parties and a mutually acceptable fixed or percentage fee; or .4 as provided in Section A.7.3.6. § A,7.3.4 Upon receipt of a Construction Change Directive, the Design -Builder shall promptly proceed with the change in the Work involved and advise the Owner of the Design -Builder's agreement or disagreement with the method, if any, provided in the Construction Change Directive for determining the proposed adjustment in the Contract Sum or Contract Time. § A.7.3.5 A Construction Change Directive signed by the Design -Builder indicates the agreement of the Design - Builder therewith, including adjustment in Contract Sum and Contract Time or the method for determining them. Such agreement shall be effective immediately and shall be recorded as a Change Order. § A.7.3.6 If the Design -Builder does not respond promptly or disagrees with the method for adjustment in the Contract Sum, the method and the adjustment shall be determined by the Owner on the basis of reasonable expenditures and savings of those performing the Work attributable to the change, including, in case of an increase in the Contract Sum, a reasonable allowance for overhead and profit. In such case, and also under Section A.7.3.3.3, the Design -Builder shall keep and present, in such form as the Owner may prescribe, an itemized accounting together with appropriate supporting data. Unless otherwise provided in the Design -Build Documents, costs for the purposes of this Section A.7.3.6 shall be limited to the following: .1 additional costs of professional services; .2 costs of labor, including social security, old age and unemployment insurance, fringe benefits required by agreement or custom, and workers' compensation insurance; .3 costs of materials, supplies and equipment, including cost of transportation, whether incorporated or consumed; .4 rental costs of machinery and equipment, exclusive of hand tools, whether rented from the Design - Builder or others; -5 costs of premiums for all bonds and insurance, permit fees, and sales, use or similar taxes related to the Work; and .6 additional costs of supervision and field office personnel directly attributable to the change. § A,7.3.7 The amount of credit to be allowed by the Design -Builder to the Owner for a deletion or change that results in a net decrease in the Contract Sum shall be actual net cost. When both additions and credits covering related Work or substitutions are involved in a change, the allowance for overhead and profit shall be figured on the basis of net increase, if any, with respect to that change. § A.7,3.8 Pending final determination of the total cost of a Construction Change Directive to the Owner, amounts not in dispute for such changes in the Work shall be included in Applications for Payment accompanied by a Change Older indicating the parties' agreement with part or all of such costs. For any portion of such cost that remains in dispute, the Owner shall make an interim determination for purposes of monthly payment for those costs. That determination of cost shall adjust the Contract Sum on the same basis as a Change Order, subject to the right of the. Design -Builder to disagree and assert a Claim in accordance with Article A.4• § A.7.3.9 When the Owner rm(I ! % ,Y .n 1iukdrr reit; h agreement concerning the adjustments in the Contract Sum and Contract Time, or otherwise: to lreement upon the adjustments, such agreement shall be effective irnmediately and shall be recorded by preim.raJo.n and c .ccution of an appropriate Change Order. § A.7.4 MINOR CHANGES IN THE WORK § A.7.4.1 The Owner shall have authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Titre and not inconsistent with the intentof the Design -Build At n Oucurnent .01411- _.. o ----..-_--__...__._...__....._...__. fit' •rtExtti hit A_ Cap yrightO 7.09A by Thx f?r'ne:pca!': Inst!til:e of .hrcFitecls Y-0It rlgtns rQ3erve[7. Yl f: RN I W,;: -Ct•s At A' - --'Y i• � <.r � : C••� U -, rJ cpy: i:i `! 1. . 'end !ii!r_: rrN :: r'::,!.- . _ Ir;ari i;: :: rrr .: -.su!! : , ..�:, n;: ci :•�t ynC ;, ac•- rr �.. U!rtlu ..,,. :.2d r>pi,r::•rb an cr Aistrdn ;ii� n' !il;. ,� - pana!•.e� r,•d! he uru,ecu!•�c •� th=. rue;'imcr�l : 3nt 1•asihie un,:�� Eh= lei•. Th;,' !u:::ei:� 17 Yla: , iidur VY L'lIA ilE'.. .r•li_.. ,..: .;IL q:>: tlr "•'C -OT, r,i • . c•r, ir'l.^,,'>O:Jfi f'o tai -Shc` Documents. Such changes shall be effected by written order and shall be binding on the Design-Builder. The Design-Builder shall carry out such written orders promptly. ARTICLE AA TIME § A-8.1 DEFINITIONS § A.8.1.1 Unless otherwise provided, Contract Time is the period of time, including authorized adjustments, allotted in the Design-Build Documents for Substantial Completion of the Work. § A.8.1.2 The date of commencement of the Work shall be the date stated in the Agreement unless provision is made for the date to be fixed in a notice to proceed issued by the Owner. § A.8.1.3 The date of Substantial Completion is the date determined by the Owner in accordance with Section A.9.8. § A.8.14 The term "day" as used in the Design-Build Documents shall mean calendar day unless otherwise specifically defined. § A.8.2 PROGRESS AND COMPLETION § A.8.21 Time limits stated in the Design-Build Documents are of the essence of the Design-Build Contract. By executing the Design-Build Contract, the Design-Builder confirms that the Contract Time is a reasonable period for performing the Work. § A.8.2.2 The Design-Builder shall not knowingly, except by agreement or instruction of the Owner in writing, Prematurely commence construction operations on the site or elsewhere prior to the effective date of insurance required by Article A.I l to be furnished by the Design-Builder and Owner. The date of commencement of the Work shall not be changed by the effective date of such insurance. Unless the date of commencement is established by the Design-Build Documents or a notice to proceed given by the Owner, the Design-Builder shall notify the Owner in writing not less than five days or other agreed period before commencing the Work to permit the timely filing of mortgages, mechanic's liens and other:security interests. § A-8.2,3 The Design-Builder shall proceed expeditiously with adequate forces and shall achieve Substantial Completion within the Contract Time. § A,8.3 DELAYS AND EXTENSIONS OF TIME § A.8.3A If the Design-Builder is delayed at any time in the commencement or progress of the Work by an act or neglect of the Owner or of a separate contractor employed by the Owner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Design-Builder's control, or by delay authorized by the Owner pending resolution of disputes pursuant to the Design-Build Documents, or by other causes which the Owner determines may justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Owner may determine. § A.8.3.2 Claims relating to time shall be made in accordance with applicable provisions of Section A.4.1.7. § A-8.3.3 This Section A.8.3 does not preclude recovery of damages for delay by either party under other provisions of the Design-Build Documents. ARTICLE A.9 PAYMENTS AND COMPLETION § A,9.1 CONTRACT SUM § A.9.1.1 The Contract Sum is stated in the Design-Build Documents and, including authorized adjustments, is the total amount payable by the Owner to the Design-Builder for performance of the Work under the Design-Build Documents. § A.9.2 SCHEDULE Of VALUES § A.9.2A Before the first Application for Payment, where the Contract Sum is based upon a Stipulated Sum or the Cost of the Work plus Contractor's Fee with a Guaranteed Maximum Price, the Design-Builder shall submit to the Owner an initial schedule of values allocated to various portions of the Work prepared in such form and supported by such data to substantiate its accuracy as the Owner may require. This schedule, unless objected to by the Owner, - -Al 004 - xhlbA A. copyrighi 9 2004 by The American Insiilute of Architects. All rights reservers. WARNIN-G. 7hi� A!s; ars, Th3arm3nl kYi,ru � --. Doc,If,% is 1 t•r,,,. _ z ., (' � . �nqn- � � , : t rr a:;rruu Tit: at :rtscNrcr, �rco r2Dn�d,ir::�,,, �- :i:stri7unon t:' itu5 Ala' '..r::.r.:,:•:, �al.% n hon yf Pr rl, !rr:y r•:3uL i ..... _.✓:I a!r _ cinnrna Utna4ias enu w+irl t:g to llu: n:a rmuta exte,ii oos::i'ole um'!rr th=. t2�: This ao;:umen� tiv_s pr xiuc'd by .V.-r soFR:<^ . ?. n i .n 0?/..� • .,5 u,ria +.ird?� i•i7 l,!;!)i Tits i._ r;i:iC.'' axpira Urs _t!2:ti2006.'n;' i*: no! l:,: resat-. shall be used as a basis for reviewing the Design -Builder's Applications for Payment. The schedule of values may be updated periodically to reflect changes in the allocation of the Contract Sum. § A,9.3 APPLICATIONS FOR PAYMENT § A.9.3.1 At least ten days before the date established for each progress payment, the Design -B uilder shall submit to the Owner an itemized Application for Payment for operations completed in accordance with the current schedule of values. Such application shall be notarized, if required, and supported by such data substantiating the Design - Builder's right to payment as the Owner may require, such as copies of requisitions from Contractors and material suppliers, and reflecting retainage if provided for in the Design -Build Documents: § A.9.3.1,1 As provided in Section A.7.3.8, such applications may include requests for payment on account of Changes in the Work which have been properly authorized by Construction Change Directives but are not yet included in Change Orders. § A.9.3.1.2 Such applications may not include requests for payment for portions of the Work for which the Design - Builder does not intend to pay to a Contractor or material supplier or other parties providing services for the Design - Builder, unless such Work has been performed by others whom the Design -Builder intends to pay. § A.9.3.2 Unless otherwise provided in the Design -Build Documents, payments shall be made on account of materials and equipment delivered and suitably stored at the site for subsequent incorporation in the Work. If approved in advance by the Owner, payment may similarly be made for materials and equipment suitably stored off the site at a location agreed upon in writing. Payment for materials and equipment stored on or off the site shall be conditioned upon compliance by the Design -Builder with procedures satisfactory to the Owner to establish the Owner's title to such materials and equipment or otherwise protect the Owner's interest and shall include the costs of applicable insurance, storage and transportation to the site for such materials and equipment stored off the site. § A.9.3.3 The Design -Builder warrants that title to all Work other than Instruments of Service covered by an Application for Payment will pass to the Owner no later than the time of payment. The Design -Builder further warrants that, upon submittal of an Application for Payment, all Work for which Certificates for Payment have been previously issued and payments received from the Owner shall, to the best of the Design -Builder's knowledge, information and belief, be free and clear of liens, Claims, security interests or encumbrances in favor of the Design - Builder, Contractors, Subcontractors, material suppliers, or other persons or entities making a claim by reason of having provided labor, materials and equipment relating to the Work. § A.9.4 ACKNOWLEDGEMENT OF APPLICATION FOR PAYMENT § A.9.4.1 The Owner shall, within seven days after receipt of the Design -Builder's Application for Payment, issue to the Design -Builder a written acknowledgement of receipt of the Design -Builder's Application for Payment indicating the atnount the Owner has determined to be properly due and, if applicable, the reasons for withholding payment In whole or in part. § A.9.5 DECISIONS TO WITHHOLD PAYMENT § A,9.5.1 The Owner may withhold a payment in whole or in part to the extent reasonably necessary to protect the Owner due to the Owner's determination that the Work has not progressed to the point indicated in the Application for Payment or that the quality of Work is not in accordance with the Design -Build Documents. The Owner may also withhold a payment or, because of subsequently discovered evidence, may nullify the whole or a part of an Application for Payment previously issued to such extent as may be necessary to protect the Owner froth loss for which the Design -Builder is responsible, including loss resulting from acts and omissions, because of the following: .1 defective Work not remedied; .2 third -party claims filed or reasonable evidence indicating probable filing of r;uch claims unless security acceptable to the Owner is provided by the Design -Builder; .3 failure of the Design -Builder to make payments properly to Contractors or for design services labor, materials or equipment; .4 reasonable evidence that the Work cannot be completed for the unpaid balance of the Contract Sum; .5 damage .6 the Owner or a separate contractor; reasonable evidence that the Work will not be completed within the Contract Time and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; or A IA DUCUrneo? A141 TV -- 2004 Exhibit A. Copyright �0 2004 by The An1Brican Inslitute of Architects. Aft rig Ms reserved WARNING: rius AIA' - �'.'r<iatre?r;fiiiprC..._._ ,f'1 - con•7ri,'p- ia", _ fl'I� ... ..,•,rl -,r_. ,.:,. :l rf Ifi ab' 11 ;�tlY. ,7ii'_. IJn3a11:;,r i; Ur,If.^.❑(, L]!':: ".,.t, :.iio;,:'Ul'� A;,r, Docum."'.. • . -,--vert. nrf !:Wr .9. p9r:�.ipt:S. ;,fair .:ill b.• pros�[.�vled Ic ire n- r� .. 19 ;vas produced by ,rA sof:' .- 3 im.; r -xk•nl ^, :U • uocf':a; :ir; f;;.•r Itus decor: t;! i_Is:.r PSo?=s. � .- •off : .. ..,n 4:'JO%°'_%�o:, sft'.e`r r+-.: pl ,prr?' , ,! f'? I rrhir`i axp•r_, <;n'i•;•ii?n0:=• dilr i.; n:a .r.. r:=sa!I:p persistent failure to carry out the Work in accordance with the Design -Build Documents. § A.9.5.2 When the above reasons for withholding payment are removed, payment will be made for amounts Previously withheld. § A.9.6 PROGRESS PAYMENTS § A.9.6.1 After the Owner has issued a written acknowledgement of receipt of the Design -Builder's Application for Payment, the Owner shall make payment of the amount, in the manner and within the time provided in the Design - Build Documents. § A.9.6.2 The Design -Builder shall promptly pay the Architect, each design professional and other consultants retained directly by the Design -Builder, upon receipt of payment from the. Owner, out of the amount paid to the Design -Builder on account of each such party's respective portion of the Workt the amount to which each such party is entitled. § A.9.6.3 The Design -Builder shall promptly pay each Contractor, upon receipt of payment from the Owner, out of the amount paid to the Design -Builder on account of such Contractor's portion of the Work, the amount to which said Contractor is entitled, reflecting percentages actually retained from payments to the Design -Builder on account Of the Contractor's portion of the Work. The Design -Builder shall, by appropriate agreement with each Contractor, require each Contractor to make payments to Subcontractors in a similar manner. § A.9.6.4 The Owner shall have no obligation to pay or to see to the payment of money to a Contractor except as may otherwise be required by law. § A.9.6.5 Payment to material suppliers shall be treated in a manner similar to that provided in Sections A.9.6.3 and A.9.6.4. § A.9.6.6 A progress payment, or partial or entire use or occupancy of the Project by the Owner, shall not constitute acceptance of Work not in accordance with the Design -Build Documents. § A.9.6.7 Unless the Design -Builder provides the Owner with a payment bond in the full penal sum of the Contract Sum, payments received by the Design -Builder for Work properly performed by Contractors and suppliers shall be held by the Design -Builder for those Contractors or suppliers who performed Work or furnished materials, or both, under contract with the Design -Builder for which payment was made by the Owner. Nothing contained herein shall require money to be placed in a separate account and not be commingled with money of the Design=Builder, shall create any fiduciary liability or tort liability on the part of the Design -Builder for breach of trust or shall entitle any person or entity to an award of punitive damages against the Design -Builder for breach of the requirements of this provision. § A.9.7 FAILURE OF PAYMENT § A.9.7.1 If for reasons other than those enumerated in Section A.9.5.1, the Owner does not issue a payment within the time period required by Section 5.1.3 of the Agreement, then the Design -Builder may, upon seven additional days' written notice to the Owner, stop the Work until payment of the amount owing has been received. The Comract'rime shall be extended appropriately and the Contract Sum shall be increased by the amount of the Design -Builder's reasonable costs cif shutdown, delay and start-up, plus interest as provided for in the Design -Build Docu nu�ta. § A.9.8 SUBSTANTIAL COMPLETION § A.9.8.1 Substantial Completion is the stage in the progress of the Work when the Work or designaiel portion thereof is sufficiently complete in accordance with the Design -Build Documents so that the Owner can occupy or use the Work or a portion thereof for its intended use. § A.9.8.2 When the Design -Builder considers that the Work, or a portion thereof which the Owner agrees to accept separately, is substantially complete, the Design -Builder shall prepare and submit to the 0%vmn a comprehensive list of items to be completed or corrected prior to final payment. F= ilure to include an item on such list does not alter the responsibility of the Design -Builder to complete all Work in accordatic,; with the Dc:sipn-Build Documents. AIA Document Al.- 2004 Exhibit A. C,u._, r .---- Arnedcp. ns -- ---(ects...--- — ARGIN ttY �h\ ra ?004 c t na Arnar'ran Institut- of Archi(eets. All .ii h!s reserved 4iP.R(:ItIG. 'nls nn '( p r,y tJ. n. Ct:pdryr ; 9 r -. n,. :. :':;ur., 4J, t!t'to: iz•ed r e,p,gduaiinr'.:,r distre butic., of ,h,s AlAv D ):.,u ieir 20fe ` .•�•� u rnap ffs....d1 in se -fere riv a vl -"� Lqy •�;n�a panr.tlies. .., . r: 41 br, ra^.:^ul^.A tc the m:-s,!rmu:r, ;rx(e:}t possible Cle ., r, [it:r in,: la.:: This drn', r was pror,'uce,� b A!fi soR.vr:}r ;;7 ? ; _ P rri.•n tJer;de�.�.r. Y ..�iII:. O;Ir,:;).r_,.al;ur,de N0":f!;0:701t_ 1:ranchnxcnr?sc};I5.2d!201i6,- :I:.'n;:rcr.<a<r't § A.9.8.3 Upon receipt of the Design -Builder's list, the Owner shall make an inspection to determine whether the 1,--.- Work or designated portion thereof is substantially complete. If the Owner's inspection discloses any item, whether or not included on the Design -Builder's list, which is not substantially complete, the Design -Builder shall complete or correct such item. In such case, the Design -Builder shall then submit a request for another inspection by the Owner to determine whether the Design -Builder's Work is substantially complete. § A.9.8.4 In the event of a dispute regarding whether the Design -Builder's Work is substantially complete, the dispute shall be resolved pursuant to Article A.4. § A.9.8.5 When the Work or designated portion thereof is substantially complete, the Design -Builder shall prepare for the Owner's signature an Acknowledgement of Substantial Completion which, when signed by the Owner, shall establish (1) the date of Substantial Completion of the Work, (2) responsibilities between the Owner and Design - Builder for security, maintenance, heat, utilities, damage to the Work and insurance, and (3) the time within which the Design -Builder shall finish all items on the list accompanying the Acknowledgement. When the Owner's inspection discloses that the Work or a designated portion thereof is substantially complete, the Owner shall sign the Acknowledgement of Substantial Completion. Warranties required by the Design -Build Documents shall commence on the date of Substantial Completion of the Work or designated portion thereof unless otherwise provided in the Acknowledgement of Substantial Completion. § A.9.8.6 Upon execution of the Acknowledgement of Substantial Completion and consent of surety, if any, the Owner shall make payment of retainage applying to such Work or designated portion thereof. Such payment shall be adjusted for Work that is incomplete or not in accordance with the requirements of the Design -Build Documents. § A.9.9 PARTIAL OCCUPANCY OR USE § A.9,9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Design -Builder, provided such occupancy or use is consented to by the insurer, if so required by the insurer, and authorized by public authorities having jurisdiction over the Work.. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Design -Builder have accepted in writing the responsibilities assigned to each of them for payments, retainage, if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for completion or correction of the Work and commencement of warranties required by the Design -Build Documents. When the Design -Builder considers a portion substantially complete, the Design -Builder shall prepare and submit a list to the Owner as provided under Section A.9.8.2. Consent of the Design -Builder to partial occupancy or use shall not be unreasonably withheld. The stage of the progress of the Work shall be determined by written agreement between the Owner and Design -Builder. § A.9.9.2 Immediately prior to such partial occupancy or use, the Owner and Design -Builder shall jointly inspect the area to be occupied or portion of the Work to be used to determine and record the condition of the Work. § A.9.9.3 Unless otherwise agreed upon, partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Design -Build Documents. § A.9.10 FINAL COMPLETION AND FINAL PAYMENT" § A.9.10.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Owner shall promptly make such inspection and, when the Owner finds the Work acceptable under the Design -Build Documents and fully performed, the Owner shall, subject to Section A.9.10.2, promptly make final payment to the Design -Builder. § A.9.10.2 t4either final payment nor any remaining retained percentage will become due until the Design -Builder submits to the Owner (1) an affidavit that payrolls, bills for inaterials and equipment, and other indebtedness connected with the Work for which the Owner or the Owner's property might be responsible or encumbered (less amounts withheld by Owner) have been paid or otherwise satisfied, (2) a certificate evidencing that insurance required by the Design -Build Documents to remain in force after final payment is currently in effect and will not be cancelled or allowed to expire until at least 30 days' prior written notice has been given to the Owner, (3) a written statement that the Design -Builder knows of no substantial reason that the insurance will not be renewable to cover the period required by the Design -Build Documents, (4) consent of surety, if any, to final payment, and (5) if required by the Owner, other data establishing payment or satisfaction of obligations, such as receipts, releases and Alyn pacument Al41'x •-2004 Exhibit A. Copyright © 2004 by The ArnFficarl Institute of Architects. All rights reserved. WARNING . Phis .al A' U.= Copy, `i1 ;_a+9 a :!nr�•r� reproduction •'A' Lwcwoe <rr• Copy, ;,� i �;ir.r.:,r i nezu:e�;. llnsutr�ori.v�d re:roduc0orz �r di,lribulion:` Illi:: r, 1 nr. r 21 p•: s pr of it, rnr � rn rel: in 53v=•r: ""' 1 and rrrnb�7.: pr:r.3the Knit � h� pr„�sacm-6 tr, She maxtrnum esaerl ❑Sfitr Lind=r tir..� Ti was pr es- 5y AI.A software at 17:07:.90 or. 02/07/2006 under order No.1000170112_1 which expires on 3/24!2006• and i ' r.ot for resale.' ' rf "uraen User Notes: (210,79300) —_I — N ,:.I:. ,<.... .. -..: r ,I , , .,... „ . ..._—i1._ i. 'L i 1 _L__. ,:.— - - ',.- L _.e. I :,`_L_ waivers of liens, claims, security interests or encumbrances arising out of the Design -Build Contract, to the extent and in such form as may be designated by the Owner. If a Contractor refuses to furnish a release or waiver required by the Owner, the Design -Builder may furnish a bond satisfactory to the Owner to indemnify the Owner against such lien. If such lien remains unsatisfied after payments are made, the Design -Builder shall refund to the Owner all money that the Owner may be liable to pay in connection with the discharge of such lien, including all costs and reasonable attorneys' fees. § A.9.10.3 If, after the Owner determines that the Design -Builder's Work or designated portion thereof is substantially completed, final completion thereof is materially delayed through no fault of the Design -Builder or by issuance of a Change Order or a Construction Change Directive affecting final completion, the Owner shall, upon application by the Design -Builder, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than retainage stipulated in the Design Build Documents, and if bonds have been furnished, the written consent of surety to payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Design -Builder. Such payment shall be made under terms and conditions governing final payment, except that it shall not constitute a waiver of claims. § A.9.10.4 The making of final payment shall constitute a waiver of Claims by the Owner except those arising from: .1 liens, Claims, security interests or encumbrances arising out of the Design -Build Documents and unsettled; .2 failure of the Work to comply with the requirements of the Design -Build Documents; or .3 terms of special warranties required by the Design -Build Documents. § A.9.10.5 Acceptance of final payment by the Design -Builder, a Contractor or material supplier shall constitute a waiver of claims by that payee except those previously made in writing and identified by that payee as unsettled at the time of final Application for Payment. ARTICLE A.10 PROTECTION OF PERSONS AND PROPERTY § A.10.1 SAFETY PRECAUTIONS AND PROGRAMS § A.10.1.1 The Design -Builder shall be responsible for initiating and maintaining all safety precautions and programs in connection with the performance of the Design -Build Contract. § A.10.2 SAFETY OF PERSONS AND PROPERTY § A.10.2.1 The Design -Builder shall take reasonable precautions for safety of, and shall provide reasonable protection to prevent damage, injury or loss to: .1 employees on the Work and other persons who may be affected thereby; .2 the Work and materials and equipment to be incorporated therein, whether in storage on or off the site or under the care, custody or control of the Design -Builder or the Design -Builder's Contractors or Subcontractors; and .3 other property at the site or adjacent thereto, such as trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction. § A.10.2,2 The Design -Builder shall give notices and comply with applicable laws, ordinances, rules, regulations and lawful orders of public authorities bearing on safety of persons or property or their protection from damage, injury or loss. § A,10,2.3 The Design -Builder shall erect and maintain, as required by existing conditions and performance of the Design -Build Documents, reasonable safeguards for safety and protection, including posting danger signs and other warnings against hazards, promulgating safety regulations and notifying owners and users of adjacent sites and utilities. § A,10.2.4 When use or storage of explosives or other hazardous materials or equipment or unusual methods are necessary for execution of the Work, the Design -Builder shall exercise utmost care and carry on such activities under supervision of properly qualified personnel. AIA Document Clti' 0U4 Exhibitp.[oaYrjntrUc0r4V The r'+m1eccanrlrUs!jhtoOfArcffCC,s All nfQhjai!lltse'vUd. 'dRYAFn i,r„�!Arl O�:.0 1 r ! i 1 !17 17 ) II n ]jr Y3tjr ,1: s VFtb - 22 1Y3 ,.war..^gid ): ��. al�ir and Crirning! 1 1 I:t - JW) Trill tt _._....,. . d Ir- Jho r.l;f :•.I^!!tm n. r+l r ossihlrr um ; u: 4 . 9! : r Qt7:?%) r r, NV,171'200o yrn;,, :iny�� n. I0. ,.� icr r idcr Thi; dC6�. _ _. f:_ C'I711 I u•1'u.^h e -.., _1-, �/?.'2QG�. a_r¢'. �.; »i; er•.r I9>, .. § A.10.2.5 The Design -Builder shall promptly remedy damage and loss (other than damage or loss insured under property insurance required by the Design -Build Documents) to property referred to in Sections A.10.2.1.2 and A.10.2.1.3 caused in whole or in part by the Design -Builder, the Architect, a Contractor, a Subcontractor, or anyone directly or indirectly employed by any of them or by anyone for whose acts they may be.liable and .for which the Design -Builder is responsible under Sections A.10.2.1.2 and A.10.2.1.3, except damage or loss- attributable to acts or omissions of the Owner or anyone directly or indirectly employed by the Owner, or by anyone for whose acts the Owner may be liable, and not attributable to the fault or negligence of the Design -Builder. The foregoing obligations of the Design -Builder are in addition to the Design -Builder's obligations under Section A.3.17. § A.10.2.6 The Design -Builder shall designate in writing to the Owner a responsible individual whose duty shall be the prevention of accidents. § A.10.2.7 The Design -Builder shall not load or permit any part of the construction or site to be loaded so as to endanger its safety. § A,10.3 HAZARDOUS MATERIALS § A.10.3.1 Ureasonable precautions will be inadequate to prevent foreseeable bodily injury or death to persons resulting from a material or substance, including but not limited to asbestos or polychlorinated biphenyl (PCB), encountered on the site by the Design -Builder, the Design -Builder shall, upon recognizing the condition, immediately stop Work in the affected area and report the condition to the Owner. § A-10,3.2 The Owner shall obtain the services of a licensed laboratory to verify the presence or absence of the material or substance reported by the Design -Builder and, in the event such material or substance is found to be present, to verify that it has been rendered harmless. Unless otherwise required by the Design -Build Documents, the Owner shall furnish in writing to the Design -Builder the names and qualifications of persons or entities who are to Perform tests verifying the presence or absence of such material or substance or who are to perform the task of removal or safe containment of such material or substance. The Design -Builder shall promptly reply to the Owner in writing stating whether or not the Design -Builder has masonable objection to tlte'persons or erttf.�ies pmpAsed by the Owner. If the Design -Builder has an objection to a person or entity proposed by the Owner, the Owner shall propose another to whom the Design -Builder has no reasonable dbjection. When. the material or substance has been tendered harmless, work in the affected area shrill resume upon written agreement of the Owner and Design -Builder. The Contract Time shall be extended appropriately, and the Contract Sum shall be increased in the amount of the Design -Builder's reasonable additional Costs of shutdown, delay and start-up, which adjustments shall be accomplished as provided in Article A.7. § A.10.3.3 To the fullest extent permitted by law, the Owner shalt indemnify and hold harmless the Design -Builder, Contractors, Subcontractors, Architect, Architect's consultants and the agents and employees of any of them from and against Claims, damages, losses and expenses, including but not limited to attorneys' fees, arising out of or resulting from performance of the Work in the affected area if in fact the material or substance exists on site as of the date of the Agreement, is not disclosed in the Design -Build Documents and presents the risk of bodily injury or death as described in Section A.10.3.1 and has not been rendered harmless, provided that such Claim, damage, loss or expense is attributable to bodily injury, sickness, disease or death or to injury to or destruction of tangible property (other than the Work itself) to the extent that such damage, loss or expense is not due to the negligence of the Design -Builder, Contractors, Subcontractors, Architect, Architect's consultants and the agents and employees of any of them. § A.10.4 The Owner shall not be responsible tinder Section A.10.3 for materials and substances brought to the site by the Design -Builder unless such materials or substances were required by the Design. -Build Documents. g A.10.5 If, without negligence on ilu_ part Or III,: DC1,1 rn flail i r, the Design -Builder is held liable for the cost of remediation of a hazardous material irr suhstanct. solely by rea on of performing Work as required by the Design - Build Documents, the Owner skull intientnify tfta Oc�ipit• Builder for all cost and expense thereby incurred. § A.10.6 EMERGENCIES § A.1 0.6.1 In an emergency affecting safety of persons or property, the Design -Builder shall act, at the Design - Builder's discretion, to prevent threatened damage, injury or loss. Additional compensation or extension of time _.- +ilk Doi;urnent A141'"^ -2004 Exhibit A, C.opyrighi !i? 200rt oy The Arrciiccrn In„tit:te M kchitects. All rights reserved. INARNIMi Tbiz; AW.' U r,.nt p ri1 (t W23 ;. j U ; :: n, 1,j�ir.,,. 1 : a.• .vi.. i [ n !;✓ -al l r.+:, r.:•:. tl. .!n ....r .0G r ;ui Jr 'r.bt:•u•t i.: tits- .i [!ff rnyf ill In :.'•rPr- itiv.!'r'W .n �Rz �.n_.!tiet -u•d •�; .I ttr c.ro5ira_•.•'1 rc ttrr., r.intur,�., I,...,�Li:�, .f: r h.c r?+:- r 23 .0 :-Jf, vil'ic-r !'tr lilf.`I?t7fi1 i ,....(.Y.. .t:s or Y21y'!i -- r -i— —..�, r-r-r—r-r.... claimed by the Design -Builder on account of an emergency shall be determined as provided in Section A.4.1.7 and Article A.7. ARTICLE A.11 INSURANCE AND BONDS § A.11.1 Except as may otherwise be set forth in the Agreement or elsewhere in the Design -Build Documents, the Owner and Design -Builder shall purchase and maintain the following types of insurance with limits of liability and deductible amounts and subject to such terms and conditions, as set forth in this Article A.11. § A.11.2 DESIGN -BUILDER'S LIABILITY INSURANCE § All 1.2.1 The Design -Builder shall purchase from and maintain in a company or companies lawfully authorized to do business in the jurisdiction in which the Project is located such insurance as will protect the Design -Builder from claims set forth below that may arise out of or result from the Design -Builder's operations under the Design -Build Contract and for which the Design -Builder may be legally liable, whether such operations be by the Design -Builder, by a Contractor or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable: .1 claims under workers' compensation, disability benefit and other similar employee benefit acts which are applicable to the Work to be performed; .2 claims for damages because of bodily injury, occupational sickness or disease, or death of the Design - Builder's employees; .3 claims for damages because of bodily injury, sickness or disease, or death of any person other than the Design -Builder's employees; .4 claims for damages insured by usual personal injury liability coverage; .S claims for damages, other than to the Work itself, because of injury to or destruction of tangible Property. including loss of use resulting therefrom; .6 claims for damages because of bodily injury, death of a person or property damage arising out of ownership, maintenance or use of a motor vehicle; .7 claims for bodily injury or property damage arising out of completed operations; and .8 claims involving contractual liability insurance applicable to the Design -Builder's obligations under Section A.3.I7. § A.11.2.2 The insurance required by Section A.11.2.1 shall be written for not less than limits of liability specified in the Design -Build Documents or required by law, whichever coverage is greater. Coverages, whether written on an occurrence or claims -made basis, shall be maintained without interruption from date of commencement of the Work until date of final payment and termination of any coverage required to be maintained after final payment. § A.11.2.3 Certificates of insurance acceptable to the Owner shall be filed with the Owner prior to commencement of the Work. These certificates and the insurance policies required by this Section A.11.2 shall contain a provision that coverages afforded under the policies will not be canceled or allowed to expire until at least 30 days' prior written notice has been given to the Owner. If any of the foregoing insurance coverages are required to remain in force after final payment and are reasonably available, an additional certificate evidencing continuation of such coverage shall be submitted with the final Application for Payment as required by Section A.9.10.2. Information concerning reduction of coverage on account of revised limits or claims paid under the General Aggregate, or both, shall be furnished by the Design -Builder with reasonable promptness in accordance with the Design -Builder's information and belief. § A,11.3 OWNER'S LIABILITY INSURANCE § A.11.3.1 The Owner shall be responsible for purchasing and maintaining the Owner's usual liability insurance. § AA 1.4 PROPERTY INSURANCE § A.11A.1 Unless otherwise provided, the Owner shall purchase and maintain, in a company or companies lawfully authorized to do business in the jurisdiction in which the Project is located, property insurance written on a builder's risk, "all-risk" or equivalent policy form in the amount of the initial Contract Sum, plus the value of subsequent Design -Build Contract modifications and cost of materials supplied or installed by others, comprising total value for the entire Project at the site on a replacement cost basis without optional deductibles. Such properly insurance shall be maintained, unless otherwise provided in the Design -Build Documents or otherwise agreed in writing by all persons and entities who are beneficiaries of such insurance, until final payment has been made as provided in Section A.9.10 or until no person or entity other than the Owner has an insurable interest in the property required by AIA Document 8141 Tu ._ <"Doa xPdialt >copyright A. O ?tH)4 hy . the American Institute of Architects. All rlgt:>.3 r 5 WARNING � lis ? I e et+l�C,. AIA .. � p qd in .,. ., te:.e: i:r r. � ) ,.., ., '•Itu� etrur.:d ire i,.,. lin-r r.l!r:;r._ .I r r t: t.aic - i � .. .. c:•:. :u:, q .. ,. ^_., [)e�lT it,rr:,g: C.i n::; 2"7 r wur.r : o:'is!tile+ :qtr' will ' ser.u•e•-i to,h[: maxir:mrr: axten: '�G!rr : +clr.. This c,�:rci�;�n: Was prt; t,ce<i t�v .. n ,,r n ;• ; o p.a. ;: :c !.i <;r PirStB... - . at 7,ln r• !J'r-.ir? ...ptJg't: '?rrJ.r r'::T :0001,7;)11^_! =•he;:i ExCa:3" .. _•!120Cc, ar:d L ori: !u.:nssr�. this Section A.11.4 to be covered, whichever is later. This insurance shall include interests of the Owner, Design - Builder, Contractors and Subcontractors in the Project. § A.11A1.1 Property insurance shall be on an "all-risk" or equivalent policy form and shall include, without limitation, insurance against the perils of fire (with extended coverage) and physical loss or damage including, without duplication of coverage, theft, vandalism, malicious mischief, collapse, earthquake, flood, windstorm, falsework, testing and startup, temporary buildings and debris removal, including demolition occasioned by enforcement of any applicable legal requirements, and shall cover reasonable compensation for Design -Builder's services and expenses required as a result of such insured loss. § A.11.4.1.2 If the Owner does not intend to purchase such property insurance required by the Design -Build Contract and with all of the coverages in the amount described above, the Owner shall so inform the Design -Builder in writing prior to commencement of the Work. The Design -Builder may then effect insurance that will protect the interests of the Design -Builder, Contractors and Subcontractors in the Work, and, by appropriate Change Order, the cost thereof shall be charged to the Owner. If the Design -Builder is damaged by the failure or neglect of the Owner to purchase or maintain insurance as described above without so notifying the Design -Builder in writing, then the Owner shall bear all reasonable costs properly attributable thereto. § A.11A.1.3 If the property insurance requires deductibles, the Owner shall pay costs not covered because of such deductibles. § A.11.4.1.4 This property insurance shall cover portions of the Work stored off the site and also portions of the Work in transit. § A11.4.1.5 Partial occupancy or use in accordance with Section A.9.9 shall not commence until the insurance company or companies providing property insurance have consented to such partial occupancy or use, by endorsement or otherwise. The Owner and the Design -Builder shall take reasonable steps to obtain consent of the insurance company or companies and shall, without mutual written consent, take no action with respect to partial occupancy or use that would cause cancellation, lapse or reduction of insurance. § A.11.4.2 Boller and Machinery Insurance. The Owner shall purchase and maintain boiler and machinery insurance required by the Design -Build Documents or by law, which shall specifically cover such insured objects during installation and until final acceptance by the Owner; this insurance shall include interests of the Owner, Design - Builder, Contractors and Subcontractors in the Work, and the Owner and Design -Builder shall be named insureds. § A,11.4.3 Loss of Use Insurance. The Owner, at the Owner's option, may purchase and maintain such insurance as will insure the Owner against loss of use of the Owner's property due to fire or other hazards, however caused. The Owner waives all rights of action against the Design -Builder, Architect, the Design -Builder's other design professionals, if any, Contractors and Subcontractors for loss of use of the Owner's property, including consequential losses due to fire or other hazards, however caused. § A.11.4.4 If the Design -Builder requests in writing that insurance for risks other than those described herein or other special causes of loss be included in the property insurance policy, the Owner shall, if possible, include such insurance, and the cost thereof shall be charged to the Design -Builder by appropriate Change Order. § A.11.4.5 If during the Project construction period the Owner insures properties, real or personal or both, at or adjacent to the site by property insurance tinder policies separate from those insuring the Project, or if after final payment property insurance is to be provided on the completed Project through a policy or policies other than those insuring the Project daring the construction period, the Owner shall waive all rights in accordance with the terms of Section A. 11.4.7 for damages caused by fire or other causes of loss covered by this separate property insurance. All separate policies shall provide this waiver of subrogation by endorsement or otherwise. § A.11.4.6 Before an exposure to loss may occur, the Owner shall file with the Design -Builder a copy of each policy that includes insurance coverages required by this Section A.11.4. Each policy shall contain all generally applicable conditions, definitions, exclusions and endorsements related to this Project. Each policy shall contain a provision that the policy will not be canceled or allowed to expire and that its limits will not be reduced until at least 30 days' prior written notice has been given to the Design -Builder. AIA Document A141 rw - 2004 Exhibit A. Copyright © 2004 by The Americar, institute of Architects. All rights reserved. I'VARNING Tits p.!A tio;;l:m.znt is erGL.cl+ by tJ s t:,;l:yrighl lw: rrettie_;. tlnaulhor::e.q reproduction or ciistr+hutio,. c; :hi, :UA' porbrn e' it, may in s.=.v re C;1-11 30d crnr•tnal p>:..Ihn,:. ,ani! :viii be txoiec u„ tl la thu max m:rr+ er.leni puss i;i ,m,d=- the L; ,. (; is;lorr;men' �� vias 190dured by AIA. sot!.::_r_ ji 1 1:,7?; ;;, on 02;0 7"21 qn• Cirr3>,r �i,i ilJ1C+i'(J! ! 19t}:ir.h s,tpir::S pn 912'{/20Cc ..r•d :'_ c: -i ior {?tilt :r938t1 i § A.11.4.7 Waivers of Subrogation, The Owner and Design -Builder waive all rights against each other and any of their consultants, separate contractors described in Section A.6.1, if any, Contractors, Subcontractors, agents and employees, each of the other, and any of their contractors, subcontractors, agents and employees, for damages caused by fire or other causes of loss to the extent covered by property insurance obtained pursuant to this Section A.11.4 or other property insurance applicable to the Work, except such rights as they have to proceeds of such insurance held by the Owner as fiduciary. The Owner or Design -Builder, as appropriate, shall require of the separate contractors described in Section A.6.1, Warty, and the Contractors, Subcontractors, agents and employees of any of them, by appropriate agreements, written where legally required for validity, similar waivers each in favor of other Parties enumerated herein. The policies shall provide.suc:h waivers of subrogation by endorsement or otherwise. A waiver of subrogation shall be effective as to a person or entity even though that person or entity would otherwise have a duty of indemnification, contractual or otherwise, even though the person or entity did not pay the insurance premium directly or indirectly, and whether or not the person or entity had an insurable interest in the property damaged. § A.11.4.8 A loss insured under Owner's property insurance shall be adjusted by the Owner as fiduciary and made Payable to the Owner as fiduciary for the insureds, as their interests may appear, subject to requirements of any applicable mortgagee clause and of Section A.11.4.10. The Design -Builder shalt pay Contractors their just shares of insurance proceeds received by the Design -Builder, and, by appropriate agreements, written where legally required for validity, shall requite Contractors to make payments to their Subcontractors in similar manner. § A.11.4.9 If required in writing by a party in interest, the Owner as fiduciary shall, upon occurrence of an insured loss, give bond for proper performance of the Owner's duties. The cost of required bonds shall be charged against proceeds received as fiduciary: The Owner shall deposit in a separate account proceeds so'recellyed, which the Owner shall distii6ute fit.. Wdance with such agreement as the parties in interes4. tnax reach. if after such loss no other specement fdam ee 3s.iiiiade and unless the Owner terminates the Design -Build Contract fprconwatience, replacement of damaged property shall be performed by the Design -Builder after notification of a Change in the Work in accordance with Article A.7. § A:11,43-0 The Owner as fiduciary shall have power to adjust and settle.a loss with insurers unless one of the parties in interest shall ofiject .in writing within five days.after gccurrence'of loss tolhe Owner's exercise of this power.; The Owner as fiduciary shall, in the case of a decision or award, [Hake settlement with insurers in accordance with directions of a decision or award. If distribution of insurance proceeds by arbitration is required, the arbitrators will direct such distribution. § A.11.5 PERFORMANCE BOND AND PAYMENT BOND § A.11.5.1 The Owner shall have the right to require the Design -Builder to furnish bonds covering faithful performance of the Design -Build Contract and payment of obligations arising thereunder, including payment to design professionals engaged by or on behalf of the Design -Builder, as stipulated in bidding requirements or specifically required in the Agreement or elsewhere in the Design -Build Documents oil the date of execution of the Design -Build Contract. ARTICLE A.12 UNCOVERING AND CORRECTION OF WORK § A.12,1 UNCOVERING OF WORK § A.12.1.1 If a portion of the Work is covered contrary to requirements specifically expressed in the Design -Build Documents, it must be uncovered for the Owner's examination and be replaced at the Design -Builder's expense without change in the Contract Time.. § A.12.1.2 If a portion of the Work has been covered which the Owner has not specifically requested to examine. prior to its being covered, the Owner may request to see such Work and it shall be uncovered by the Design -Builder. If such Work is in accordance with the Design•l3uiid Docum.utt , c w4ts of uncovering and replacement shall, by appropriate Change Order, be.at the Owner's exu(nse, II SUCK 4 ods is not in accordance with the Design -Build Documents, correction shall be at the L)e-igr1_E3uiidcr's expense ,finless the condition was caused by the Owner or a separate contractor, in which event the Owner shall be responsible for payment of such costs. § A.12.2 CORRECTION OF WORK § A.12.2,1 BEFORE OR AFTER SUBSTANTIAL COMPLETION, T , Af'. Da:.umert .A.14T rr, _ 2004 Exhibit A. COPP i ` ht n -- I -- ----- ' g 2004 by rhe ArnFjrkan Institute or Architects. AH rights reserved WARNING: This A!A pCr,ir�n of it n' (,t."1.4." U 5 Ccpyrighi 1.I;: And lw,e mlionn' Yreal,-r=. lina�,lhon,.•,; r,.�rr .,._ 1!_•n w dist "hot. -on :}t this Ate,! . _::,ne::, Ur d, 26 i ware crud and i r u :! '�e;td'GNS, dt`C: WI:: I:F iiostr.:ut=; Ihn rnu;; ;Harr. , n! p;,,�..rina t' rii�r the. 1'hi- aua:rr ^n'. il, =a,du:•.. f 4�. tri ^ £ti 110' 1G ur +2, r YAf tr.'d 'l d:=. (,o : r'rrt'r,I I or , a0:v .':d i> for § AA2.2.1.1 The Design -Builder shall promptly correct Work rejected by the Owner or failing to conform to the y. requirements of the Design -Build Documents, whether discovered before or after Substantial Completion and whether or not fabricated, installed or completed. Costs of correcting such rejected Work, including additional testing, shall be at the Design -Builder's expense. § Al2.2.2 AFTER SUBSTANTIAL COMPLETION § A,12,2.2.1 In addition to the Design -Builder's obligations under Section A.3.5, if, within one year after the date of Substantial Completion or after the date for commencement of warranties established under Section A.9.8.5 or by terms of an applicable special warranty required by the Design�Build Documents, any of the Work is found to be not in accordance with the requirements of the Design -Build Doi:uments, the Design -Builder shall correct It promptly after receipt of written notice from the Owner to do so unless the Owner has previously given the Design -Builder a written acceptance of such condition. The Owner shall give such notice promptly after discovery of the condition. During the one-year period for correction of Work, if the Owner fails to notify the Design -Builder and give the Design -Builder an opportunity to make the correction, the Owner waives the rights to require correction by the Design -Builder and to make a claim for breach of warranty. If the Design -Builder fails to correct non -conforming Work within a reasonable time during that period after receipt of notice from the Owner, the Owner may correct it in accordance with Section A.2.5. § A.12.2.2.2 The one-year period for correction of Work shall be extended with respect to portions of Work first performed after Substantial Completion by the period of time between Substantial Completion and the actual performance of the Work. § A.12.223 The one-year period for correction of Work shall not be extended by corrective Work performed by the Design -Builder pursuant to this Section A.12.2. § A.12.2.3 The Design -Builder shall remove from the site portions of the Work which are not in accordance with the requirements of the Design -Build Documents and are neither corrected by the Design -Builder nor accepted by the Owner. § A.12.2.4 The Design -Builder shall bear the cost of correcting destroyed or damaged construction, whether completed or partially completed, of the Owner or separate contractors caused by the Design -Builder's correction or removal of Work which is not in accordance with the requirements of the Design -Build Documents. § AA 2.2.5 Nothing contained in this Section A.12.2 shall be construed to establish a period of limitation with respect to other obligations the Design -Builder .might have under the Design -Build Documents. Establishment of the one- year period for correction of Work as described in Section A. 12.2.2 relates only to the specific obligation of the Design -Builder to correct the Work, and has no relationship to the time within which the obligation to comply with the Design -Build Documents may be sought to be enforced, nor to the time within which proceedings may be commenced to establish the Design -Builder's liability with respect to the Design -Builder's obligations other than specifically to correct the Work. § A.12.3 ACCEPTANCE Of NONCONFORMING WORK § A.12.3.1 if the Owner prefers to accept Work not in accordance with the requirements of the Design -Build Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be equitably adjusted by Change Order. Such adjustment shall be effected whether or not final payment has been made. ARTICLE A.13 MISCELLANEOUS PROVISIONS § A.13.1 GOVERNING LAW § A•13.1.1 The Design -Build Contract shall be governed by the lave of the place where the Project is located. § A.13.2 SUCCESSORS AND ASSIGNS § A.13.2.1 The Owner and Design -Builder respectively bind themselves, their partners, successors, assigns and legal representatives to the other party hereto and to partners, successors, assigns and legal representatives of such other party in respect to covenants, agreements and obligations contained in the Design -Build Documents. Except as provided in Section A. 13.2.2, neither party to the Design -Build Contract shall assign the Design -Build Contract as a ---------...... - ----- -- AlA Dcun1er,2 Ata -i'%•' •- 2004 Exi?ibit A. Copyrigai U 2(JD4i by ,-!..e Amerierw Institute of :1r;t;leel.;. A!1 rig Sas reserved. •diAlaa!»G. This AiA' � •_.__... _.. Ih::1 n.0 �N•i�'�L�•,-, . ,.... . �. � � :.ir ... � .n:, ....�_.-,al .. _alp.:. l.i.,..;nn':__ i r-.� _.,.. .. ...r ry ih:::viti�. iJ : � :k'•�' -.. .r - 2 �a.;t O 7 it .. E::1 s.�..Ll .>ofl r. 3; :: :i, lu .. .. - r •� ... i � ..I-.. ,•_lni. _. • whole without written consent of the other. if either party attempts to make such an assignment without such consent, that party shall nevertheless remain legally responsible for all obligations under the Design -Build Contract. § A.13.2.2 The Owner may, without consent of the Design -Builder, assign the Design -Build Contract to an institutional lender providing construction §nancing for the Project. In such event, the lender shall assume the Owner's rights and obligations under -ft Dosign-guild Documents. The Design -Builder shall execute all consents reasonably required to fadilitate such assignment. § A.13,3 WRITTEN NOTICE § A.13.3.1 Written notice shall be deemed to have been duly served if delivered in person to the individual or a member of the firm or entity or to an officer of the corporation for which it was intended, or if sent by registered or certified mail to the last business address known to the party giving notice. § A.13.4 RIGHTS AND REMEDIES § A.13.4.1 Duties and obligations imposed by the Design -Build Documents and rights and remedies available thereunder shall be in addition to and not a limitation of duties, obligations, rights and remedies otherwise imposed or available by law. § A.13.4.2 No action or failure to act by the Owner or Design -Builder shall constitute a waiver of a right or duty afforded them under the Design -Build Documents; icor iQ1. Such action or failure to act constitute approval of or acquiescence in a breach.thereunder..exeept as maybe specifi6ily-agreed in writing. § A.13,5 TESTS AND INSPECTIONS § A.13.5.1 Tests, inspections 0id approvals of portions of the Work required by the Design -Build Documents or by laws, ordinances, rules, regti]s W& or otilft of'public:authorities having jurisdiction shall be made at an appropriate time. Unless otherwise.prOvid0d, the Design Builder "ll make arrangements for such tests, inspections and approvals. with an indepeititent testing ]abai-atory tJr..etttity acceptable to the Owner or with the appropriate public autho;ity.,qud shall behr-all relAted COW of tditts,19spections and approvals. The Design Builder shall give timely -notice of: When and where tests and inspeotiotis are to be made so that the Owner may be present for such procedures. § A.13.5.2 If the Owner or public authorities having jurisdiction determine that portions of the Work require additional testing, inspection or approval not included under Section A.13.5.1, the Owner shall in writing instruct the Design -Builder to make arrangements for such additional testing, inspection or approval by an entity acceptable to the Owner, and the Design -Builder shall give timely notice to the Owner of when and where tests and inspections are to be made so that the Owner may be present for such procedures. Such costs, except as provided in Section A.13.5.3, shall be at the Owner's expense. § A.13.5.3 If such procedures for testin.-, inspection or approval under Sections A.13.5.1 and A.13.5.2 reveal failure of the portions of the Work, to comply with requirements established by the Design -Build Documents, all costs made necessitry by such failure, including diose of repeated procedures, shall be at the Design -Builder's expense. § A.13.5.4 Required certificates of testing, inspection or approval shall, unless otherwise required by the Design - Build Documents, be secured by the Design -Builder and promptly delivered to the Owner. § A.13.5.5 If the Owner is to observe tests, inspections or approvals required by the Design -Build Documents, the Owner will do so promptly and, where practicable, at the normal place of testing. § A.13.5.6 Tests or inspections conducted pursuant to the Design -Build Docutnenls shall be made promptly to avoid unreasonable delay in the Work. § A.13.6 COMMENCEMENT OF STATUTORY LIMITATION PERIOD § A-13.6.1 As between the Owner and Design -Builder: .1 Before Substantial Completion. As to acts or failures to act occurring prior to the relevant date of Substantial Completion, any applicable statute of limitations shall continence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than such date of Substantial Completion, - a Dact+i-hent A14I N - 2004 Exhibit A. Copyright ©?004 by The American institule of Architects. All riclitiis reserved. 4YAFtlIFIG: -n+s nlA` t�oa�ume•rt Jtrr,,l9Ctvio by U S Copyright t. 3;y artd ht:ernaliatial 'ir 'r U, is unaulhu;l,;d ief:oeuctlun o, 2�a I", -lion of it ri,ty restrL [. ,r.y.;.e civil :ind crirn; a t_i ne rallies, and vrin c e pro,ocu red to th= r*!a•r.r�-urc: :; ei�•^t c053:F,t� , Baas proeh:eud t:'; r>,1? ;_ ,...,i ' t:;)?:•t': cv, 027p7,•col'�E �.•;f.:, rrr a r; �'e.:ne- l:,•r: Ti!i:; d�cw�sn� l i }OJ 01 1._ 1 !,:.t :., orraz; w: 3'2•t,.OG;,, } ,5 .. f s ;a! .2 Between Substantial Completion and Final Application for Payment. As to acts or failures to act occurring subsequent to the relevant date of Substantial Completion and prior to issuance of the final Application for Payment, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than the date of issuance of the final Application for Payment; and .3 After Final Application for Payment. As to acts or failures to act occurring after the relevant date of issuance of the final Application for Payment, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than the date of any act or failure to act by the Design -Builder pursuant to any Warranty provided under Section A.3.5, the date of any correction of the Work or failure to correct the Work by the Design -Builder under Section A.12.2, or the date of actual commission of any other act or failure to perform any duty or obligation by the Design -Builder or Owner, whichever occurs last. ARTICLE A.14 TERMINATION OR SUSPENSION OF THE DESIGN/BUILD CONTRACT SAA 4A TERMINATION BY THE DESIGN -BUILDER § A,14.1.1 The Design -Builder may terminate the Design -Build Contract if the Work is stopped for a period of 30 consecutive days thiough no act or Fault of the Design-Byilder or a Contractor, Subcontractor or their agents or ennployees orally other persnn$ gr-entitics petforniI g portions of the Work under direct or indirect contract with the DeAp-Btiflder, for' any of the following reasons: .1 issuance of an order of a court or other public authority having jurisdiction which requires all Work to be stopped; .2 an act of government, such as a declaration of national emergency which requires all Work to be stopped; .3 the Owner has failed to make payment to the Design -Builder in accordance with the Design -Build Documents; or .4 the Owner has failed to furnish to the Design -Builder promptly, upon the Design -Builder's request, reasonable evidence as required by Section A.2.2.8. §.A.14.1.2TbP Design -Builder may terminate the Design -Build Contract if, through no act or fault of the Design - Builder otr a Contractor. Subcontractor or their -agents or employees or any other persons or entities performing portions of the Work under direct or indirect contract with the Design -Builder, rp ea suspensions, delays or interruptions of the entire Work by the Owner, as described in Section A.14.3, constitute in the aggregate more than 100 percent of the total number of days scheduled for completion, or 120 days in any 365 -day period, whichever is less. § A.14.1.3 If one of the reasons described in Sections A. 14. 1.1 or A.14.1.2 exists, the Design -Builder may, upon seven days' written notice to the Owner, terminate the Design -Build Contract and recover from the Owner payment for Work executed and for proven loss with respect to materials, equipment, tools, and construction equipment and machinery, including reasonable overhead, profit and damages. § A.14.1.4 If the Work is stopped for a period of 60 consecutive days through no act or fault of the Design -Builder or a Contractor or their agents or employees or any other persons performing portions of the Work under a direct or indirect contract with the Design -Builder because the Owner has persistently failed to fulfill the Owner's obligations under the Design -Build Documents with respect to matters important to the progress of the Work, the Design - Builder may, upon seven additional days' written notice to the Owner, terminate the Design -Build Contract and recover from the Owner as provided in Section A.14.1.3. § A.14.2 TERMINATION BY THE OWNER FOR CAUSE § A.1.4,2.1 The Owner may terminate the Design -Build Contract ifthe Design -Builder: .1 persistently or repeatedly refuses or fails to supply enough properly skilled workers or proper materials; .1 fails to make payment to Contractors for services, materials or labor in accordance with the respective agreements between the Design -Builder and the Architect and Contractors; .3 persistently disregard, laws, ordinances or rules, regulations or orders of a public authority having jurisdiction; or 4 otherwise is guilty ol'substantial breach of a provision of the Design -Build Documents. AM ocurnegt A141 T — 2004 Exhibit A. CopyrigPrl 0 2OD-11 by rhe Arnericar. Institule d Architects. All rights reserved. WARNING 1r,,•; A'A" ...'..::�C."r•: !i : _`e G"i lad:; ;: S' !! S C ' r:' 11 I-ire3rEtb Ur13 t;t ll:. ni.l!t) r r)!:,. �r+b d: 1.ttc: vn:! t'tt:a!i811q+.� auc. curt or tiiglrlt:: i�:v, 47.` IN•; At." v��:: d, of '.J:rray resu;l . , ,awxc: rr;-t and crimi•:a t;i-- ars;J vii4 br. is >sc!:utc:d t:. !h^ m; , +! !rt: ,y29 1e - { Y-1".:1PIi E'7.'L'•'•`r i•;!:1..:... .:flr,')i itis, (1I!2 71 i L' 'U t!^.:r:?/!77;?(SCEs r ei y'.irrle' t'�', 1 � , "' 1 i? I +v'.i,:ii r. , n : n.1 7'? 1'P 1,16 a ; a.' Ilse! F ,ta+..: :5 t icy .. . �, - — l 41 , �. 1 1: L , . ,l 1 § A.14.2.2 When any of the above reasons exist, the Owner may without prejudice to any other rights or remedies of the Owner and after giving the Design -Builder and the Design -Builder's surety, if any, seven days' written notice, terminate employment of the Design -Builder and may, subject to any prior rights of the surety. .1 take possession of the site and of all materials, equipment, tools, and construction equipment and machinery thereon owned by the Design Builder; .2 accept assignment of contracts. pursuant to Section A.5.5.1; and .3 finish the Work by whatever reasonable method the Owner may deem expedient. Upon request of the Design -Builder, the Owner shall furnish to the Design -Builder a detailed accounting of the costs incurred by the Owner in finishing the Work. § AA4.2.3 When the Owner terminates the Design -Build Contract for one of the reasons stated in Section A.14.2.1, the Design -Builder shall not be entitled to receive further payment until the Work is finished. § A-14-2.4 If the unpaid balance of the Contract Sum exceeds costs of finishing the Work and other damages incurred by the Owner and not expressly waived, such excess shall be paid to the Design -Builder. If such costs and damages exceed the unpaid balance, the Design -Builder shall pay the difference to the Owner. § A.14.3 SUSPENSION BY THE OWNER FOR CONVENIENCE § A.1411 The Owner may, without cause, order the Design -Builder in writing to suspend, delay or interrupt the Work in whole or in part for such period of time as the Owner may determine. § A.14.3.2 The Contract Sum and Contract Time shall be adjusted for increases in the cost and time caused by suspension, delay or interruption as described in Section A.14.3.1. Adjustment of the Contract Sum shall include profit. No adjustment shall be made to the extent: .1 that performance is, was or would have been so suspended, delayed or interrupted by another cause for which the Design -Builder is responsible; or .2 that an equitable adjustment is made or denied under another provision of the Design -Build Contract. § A.14.4 TERMINATION BY THE OWNER FOR CONVENIENCE § A.14.4.1 The Owner may, at any time, terminate the Design -Build Contract for the Owner's convenience and without cause. § A.14.4.2 Upon receipt of written notice from the Owner of such termination for the Owner's convenience, the Design -Builder shall: .1 cease operations as directed by the Owner in the notice; .2 take actions necessary, or that the Owner may direct, for the protection and preservation of the Work; and .3 except for Work directed to be performed prior to the effective date of termination stated in the notice, terminate all existing contracts and purchase orders and enter into no further contracts and purchase orders. § A.14.4.3 In the event of termination for the Owner's convenience prior to commencement of construction, the, Design -Builder shall be entitled to receive payment for design services performed, costs incurred by reason of such termination and reasonable overhead and profit on design services not �.rarnplct�d. In case of termination for the Owner's convenience after commencement of construction, the Design -Builder sh=ill be entitled to receive payment for Work executed and costs incurred by reason of such termination, along with reasonable overhead and profit on the Work not executed. AIA OOCU -16;li A 11.11 M _ 2004 vvt li: l A. p;,.luttt @ 20J .. ' c A:7t> cts. -- -----a nese _... t t, r] . n by The -:;rzn 6isliiute of Architects, All right reserved Si':. g ltt If,, S' i' ,'i'7n � J ^nt: f:a`. I .1 '. i ... ! 1 d t.l �t1r9r11 .: i. :,n •)! �i:�k V)�.1;^fi ;;r l It 1� '1 ... }� ,)s-11 r •..A Fn:. .�. '. _�•l�li ) I .. „ I JtJ r•:]'I:f'.11.'- :Irilt f'S^'ihV• ft F'• T'lis :..�C 'SFr,. 3V AMENDMENT TO THE STANDARD FORM OF AGREEMENT BETWEEN OWNER AND DESIGN -BUILDER AIA A141-2004 Exhibit A ARTICLE A.2 OWNER A.2.2.8 — Delete the entire paragraph. ARTICLE A.7 CHANGES IN WORK A.7.3.6 Revise the paragraph to read: "...in case of an increase in Contract Sum, an amount for overhead and profit not to exceed fifteen percent (15%) of the net cost of the change. In such case..." A.7.3.8 Insert "approved and executed" before the term "Change Order" in the first and third sentence. ARTICLE A.9 PAYMENTS AND COMPLETION A.9.3 APPLICATIONS FOR PAYMENT A.9.3.1 Change "retainage if provided for in the Design -Build Documents" to "retainage as stipulated in Subparagraph 9.3.4." A.9.3.1.1 Delete the entire paragraph. A.9.3.4 Add Subparagraph 9.3.4 as follows: "The Owner shall retain ten percent (10%) from each Application for Payment up to fifty percent (50%) completion of the Work, then, provided the Work is on schedule and satisfactory, and upon written request of the Design -Builder, the Owner shall approve reduction in retainage to five percent (5%) of the Contract Sum. No part of the five percent (5%) retainage shall be paid until after Substantial Completion of the Work, as defined in Section 9.8. After Substantial Completion, if reasons for reduction of the retainage are approved by the Owner, a reduction to a lump sum amount less than the five percent (5%) retainage may be approved by the Owner when deemed reasonable. The minimum lump sum amount shall be twice the estimated cost to correct deficient or incomplete work." A.9.6 PROGRESS PAYMENTS A.9.6.1 Revise the paragraph to read: "...within the time provided in the Design -Build Documents or as required by state law, whichever is more restrictive." ARTICLE A.11 INSURANCE AND BONDS A.11.1 Add the following: "Such insurance shall be no less than the following amounts: Type of Insurance Limits Worker's Compensation Statutory Commercial General Liability $3,000,000/$3,000,000 CSL Commercial Automobile Liability $1,000,000 Builders Risk (incl. earthquake and flood coverage) Full value of the contract" A.11.2 Add Paragraph 11.2 as follows: "On all general and automobile liability policies of insurance Design -Builder shall have the Owner named as an additional insured and shall further require that their liability carrier(s) notify the Owner at least thirty (30) days prior to the effective date of any change(s) in Page 1 of 2 .. ,,,k, ,,- , , , v,_i.,"e a u ,— I —, - — -- , 1 L or cancellations of said insurance policies. A current copy of the proposer's insurance certificate providing proof of insurance as stated above must be on file with the Owner." A.11.5 Delete "have the right to" from the first sentence. A.13.1 GOVERNING LAW A.13.1.1 Add Paragraph 13. 1.1 as follows: "None of the Design -Build Documents for this project shall be construed against the party preparing documents on the grounds that the party prepared or drafted the document, or any portion thereof." END OF AMENDMENT Page 2 of 2 EXHIBIT B RFP # 2013-01 DEADLINE: 2:00 p.m. Prevailing Local Time Monday, March 4, 2013 CALL CENTER DESIGN BUILD SERVICES IX EXHIBITS EXHIBIT A TELETECH BASE TECHNICAL REQUIREMENTS Scope of the Project A. The new building will be 30,000 net rentable square feet (NRSF), and will be a single story Teletech (TfEC) customer contact center. The program for these spaces will be as mutually agreed after the selection of the successful candidate. B. The Onsite Development shall assume and include, without limitation all ' earthwork, wet and dry utilities, vehicular paving, pedestrian paving, landscaping, site furnishings and other improvements necessary to comply with the Master Site Developer's requirement for the property; as well as meet local, state and Federal regulations, and generally comply with the standards of the industry for buildings of this type. Specifically, the Onsite Development shall include, at a minimum: 1. A 2" domestic waterline, 2. A 6" sanitary sewer line; 3. All fwe lines and hydrants per local jurisdictional requirements; 4. Natural gas line to and meter at the building per local authority requirements; 5. Concrete curbs and gutters; 6. Storm lines and on site detention as required by local jurisdictions; Asphalt paving per the geotechnical engineer's requirements, e Al! Storrn, watel, and sewer lap's, tap fe'::s, r1leter3 and ti- iti_. for System cperation Yarm on-site distrit;ution: 29 ,-, k.. , n ti .. I, - - --4. RFP * 2013-01 DEADLINE. 2:00 p.m. Prevailing Local Time Monday, March 4, 2013 CALL CENTER DESIGN BUILD SERVICES 9. Site lighting per IES requirements, using light poles that meet local Jurisdictional requirements; 10. Electrical distribution and primary feeds to the building; Dual entry power, 11, Fiber optic connection to the building ("Iii"); self healing, dually redundant fiber feeds 12. Landscaping & site furnishings per local jurisdictional requirements. C. The Building Core and Shell shall provide, without limitation, the substructure, superstructure, exterior closure, roof, mechanical, and electrical systems necessary to have a code compliant, heated and cooled weather tight building per standards of the industry for core and shell, ready for the tenant to begin installation of interiors. More specifically, the Building Core and Shell shall indude, at a minimum, the following components: 1. Foundations assuming the same conditions as described in the geotechnical reports from adjacent buildings; 2. Tilt -up +/_ 7_1t4!' panel structure with steel columns, bar joists and metal deck infill, 24'-0" clear; 3. 6" cast in place concrete slab floor; 4. Exterior finishes and architecture similar to the buildings in the commerce park; 5 Double aluminum storefront entrances %Mth sidelights; 6 Code required minim! ims for egress doors; RFP # 2013-01 L DEADLINE: 2:00 p.m. Prevailing Local Time Monday, March 4, 2013 CALL CENTER DESIGN BUILD SERVICES 7. TPO roof with a 20 year warranty; or regionally acceptable roofing system; 8. Two (2) 6" under -slab, longitudinal sanitary lines for use by tenant; 9. Two (2)1' under -slab, longitudinal domestic water lines for use by tenant; 10. HVAC system with 300 SF/ton of cooling, DDC control compatible and capable of handling not less than 75 zones (one point of control); 11. Fire sprinkler system per code minimums, with heads turned up plus fire pump; 1.2. Electrical system to include an 8 0 0 amp service 480v/3phase and main distribution center is included (sub -panels and breakers for tenant loads by tenant); 13. Two (2) 4" empty under -slab data cabling conduit mains w/pull tapes mains run longitudinally down the building center; 14. Fire alarm panel and core and shell fire alarm system per code minimums; and 15. The building shall achieve an Energy Star Rating per current Federal standards. 0 The Offsite Improvements shall include the improvements necessary to comply with the Master Site Developer's requirements for the property, and those required provide connection to the Onsite Development systems above to make them fully operational. The Tenant Improvements shall be included and completed in accordance with TTEC GREG) Design Standards and the delivery center will seat an estimated 400 production seals This includes :sit design, engineering;, interio construction, tele/data cabling, and other tenant casts not included vVith the Building Core anti Shell costs above. 3I RFP # 2013-01 DEADLINE; 2:00 p.m. Prevailing Local Time Monday, March 4, 2013 CALL CENTER DESIGN BUILD SERVICES F. All preconstruction and construction services typically provided by a development team for a core and shell building, including but not limited to the coordination with the tenant's design and construction team, should be included in the scope of this proposal. G. All submittals for entitlements by local authorities having jurisdiction, and the Services required to obtain those entitlements for a core and shell building shall be included in the scope of this proposal. H. Providing the building ready for occupancy on the date scheduled will be conditions of the agreement, and both win be subject to liquidated damages for failure to perform. 32 IeleCI:l_.._t all Ce„tLr Des, il_d ServcNr.s Scope of Work Dated. March 4, 2013 Division 1— General Conditions • Project Management • On Site Supervision • Architectural and Engineering Fees • Soils Report • Daily Clean Up • Final Cleaning • Layout • Tools and Equipment • Temporary Facilities • Builder's Risk Insurance • Building Permit Division 2 — Site Work • Earthwork • Storm Sewer • Asphalt Paving • Concrete Curbs • Concrete Sidewalks • Concrete Entrance • Concrete Dumpster Pad • Concrete Patio Division 3 — Concrete • Concrete Foundations • 4" Concrete Floor Slab Division 4 — Masonry • Masonry Veneer Division 5 — Structural Steel • Pre-engineered Metal Building Structure • Steel Deck Division 6 — Wood and Plastics • Rough Carpentry • Millwork Division 7 — Thermal and Moisture Protection • Building insulation • Single Ply Membrane Roofing 6FY:. hj1W IIIiARCUM WL ENGINEERING. LLC _._._. I Tele Tech C.1II Center DesiUri -----B-j,ld Seryices F — - _ ._..-------_ -- —._ ..... • Sheet Metal and Flashing • Joint Sealants Division st – Doors and Windows • Hollow Metal Doors and Frames • Solid Core Wood Doors • Aluminum Entrances and Storefronts • Aluminum Windows • Finish Hardware • Glass and Glazing Division 9– Finishes • Metal Stud Framing • Drywall • Acoustical Ceiling Tiles • Ceramic Tile in Restrooms • Resilient Floor Tile • Carpeting • Painting Division 10 – Specialties • Toilet Partitions • Interior Signage • Fire Extinguishers and Cabinets • Toilet Accessories Division 15 – Mechanical • Plumbing Fixtures • Domestic Water Piping • PVC Sanitary Sewer and Vent Piping • 2-1/2" PVC Domestic Water Service Piping Including 2" Meter • 4" Exterior PVC Sanitary Sewer Piping Including Tap Fee • Gas Piping • (10) Rooftop Package HVAC Units • (6) Ductless Split Heat Pumps • (1) Computer Room Air Conditioner • (9) Exhaust Fans • Supply, Return and Exhaust Ductwork System • Refrigerant Piping O Seismic Material and Calculations on All Duct, Pipe and Equipment m Mechanical Insulation DDC Controls • Certified Air Balance • Wet Automatic Fire Sprinkler System hOW AFlCUM Wk ENGINEEHRING, �_!_ J- ----..._.i_.-Te_IeTec h_,Ca1l Center Desigf-ti Build Services • 6" Ductile Iron Pipe Underground Fire Main Service • 4" PVC C-900 Pipe for the Remote Fire Department Connection Division 16 —_Electrical • Switchgear Package • Lighting Package • Site Lighting • Power Company Feed • Transformer Pad • Aluminum Wire and MC Cable per Code • Cable Tray • Fire Alarm System • Temporary Lighting • Temporary Power ARCUM ENGINEERING, LLC Scope of Work April 3, 2013 Desien Services • Architectural Design • Civil Engineering Design • Structural Engineering Design • Mechanical Engineering Design • Working Drawings • Soils Investigation and Report • Construction Administration/inspections Division 1— General Conditions • Project Management • On Site Supervision • Daily Clean Up • Final Cleaning • Layout • Tools and Equipment • Temporary Facilities • Builder's Risk Insurance • Payment and Performance Bond • Building Permit Division 2 — Site Work • Ea rthwork — Cut and Fill as Necessary to Balance the Site • Storm Sewer • Asphalt Paving — 8" Compacted DGA and 3" Asphalt • Post Formed Concrete Curbs • 4" Concrete Sidewalks Utilizing 4,000 psi Concrete • 6" Concrete Entrance Utilizing 4,000 psi Concrete • 6" Concrete Dumpster Pad Utilizing 4,000 psi Concrete • Topsoil Replacement • Seeding • Landscaping Allowance of $25,000.00 Division 3 —Concrete • Concrete Foundations as Shown Utilizing 4,000 psi Concrete • 4" Concrete Floor Slab Utilizing 4,000 psi Concrete Division 4 — Masonry • Brick Veneer on Exterior Walls Including $350.00/1,000 Brick Allowance Division 5 — Structural Steel • Pre-engineered Structural Steel Framing BFW MARCUM ` . ' ENGINEERING, LLC BACON I FARMER I WORKMAN ElIOINEEgIHO � IE9TINp INC T n tjuila sery • 22 ga. Steel Deck Division 6 — Wood and Plastics • Rough Carpentry Including Roof Blocking and Miscellaneous Blocking • Reception Desk—Custom Designed and Built • Plastic Laminate Break Room Counter as Shown • Plastic Laminate Restroom Vanities Division 7 — Thermal and Moisture Protection • R-38 Simple Saver Insulation System in the Roof • R-19 Batt Insulation in the Walls • 2" Exterior Insulation and Finish System • 60 -mil. TPO Membrane Roofing with 20 year Warranty • Sheet Metal and Flashing • Joint Sealants Division a- Doors and Windows • Exterior Doors to be Hollow Metal Doors and Frames • Interior Doors to be Solid Core Wood Doors and Hollow Metal Frames • Aluminum Entrances and Storefronts • Aluminum Windows • Finish Hardware • Glass and Glazing • Restroom Mirrors Division 9 — Finishes • Exterior Walls to be 12 ga. Metal Studs, 6" Batt Insulation, DensGlass Sheathing, 5/8" Drywall • Non -Load Bearing Interior Walls to be 25 ga. Metal Studs, Sound Batt Insulation, 5/8" Drywall both Sides • 2' x 2' Revealed Edge Acoustical Ceilings with 15/16" Grid at All Public Areas, Offices, Training Areas, and Conference Rooms • 2' x 2' Square Edge Acoustical Ceilings with 15/16" Grid at All Other Areas • Ceramic Tile in Restrooms and Vestibule,'$8.00/sf Installed • Resilient Floor Tile in Break Room, Comm./Elec. and Storage Closets • Carpeting in Waiting, Reception, Offices, Conference Rooms, Training, TA Staff, TA Testing, and Production Area, $27.00/sy Installed • Painting as Necessary Division 10 — Specialties • Toilet Partitions as Shown • Interior Signage as Required ® Fire Extinguishers and Cabinets per Code • Toilet Accessories as Required BFW hdW tYIARCUM ENGINEERING, LLC BACON I FARMLR! WORKMAN exam....... _. .. I— i Division 15 — Utilities • 2-1/2" PVC Domestic Water Service Piping Including 2" Meter • 6" Ductile Iron Pipe Underground Fire Main Service Including Tap and Bore Under McCracken Boulevard • 4" PVC C-900 Pipe for the Remote Fire Department Connection • 4" Exterior PVC Sanitary Sewer Piping Including Tap Fee • Natural Gas Piping Division 15 — Mechanical • Plumbing Fixtures — Flush Valve Type Toilets and Urinals • Copper Domestic Water Piping • PVC Sanitary Sewer and Vent Piping • Natural Gas Piping • (10) Rooftop Package HVAC Units • (6) Ductless Split Heat Pumps • (1) Computer Room Air Conditioner • (9) Exhaust Fans • Supply, Return and Exhaust Ductwork System — Including Duct Sock in Production Area • Refrigerant Piping • Seismic Material and Calculations on All Duct, Pipe and Equipment • Mechanical Insulation • DDC Controls • Certified Air Balance • Wet Automatic Fire Sprinkler System Division 16 — Electrical • Switchgear Package • Lighting Fixtures • Site Lighting • 800A Power Company Feed • Transformer Pad • Aluminum Wire and MC Cable per Code • Cable Tray for Data Wiring • Fire Alarm System • Temporary Lighting • Temporary Power Exceptions to the Specifications • Water heaters will be electric. Natural gas is only utilized for rooftop HVAC units. • Sub -panels and breakers shall be provided by the Contractor in lieu of the Tenant as referenced. h- dW MARCUM% BFW Ek ENGINEERING. LLC BACON I FARMER ! WORKMAN EMQIfEEN,MO! fEEi1MO ext • Fire Alarm shall be provided complete by the Contractor in lieu of the core and shell as referenced. • Height of the building is approximately 20'-0" to the roof line in lieu of 24'-0" clear height as referenced. • A 4" thick concrete slab will be provided in lieu of the referenced 6" thick concrete slab. • A 2-1/2" water line is required for the facility in lieu of the referenced 2" water line. • A 4" sanitary sewer will serve the facility in lieu of the referenced 6" sanitary sewer line. • Two (2) 6" under -slab, longitudinal sanitary lines are excluded. • Two (2) 1" under -slab, longitudinal domestic water lines are excluded. • Fire pump is excluded as that it is not required for standard 100% coverage. • Provisions for ITEC GREG Design Standards are excluded as that none were received. • Communication systems (jacks, cabling, racks, patch panels, switches, routers, phones, etc.) are excluded. • Emergency generator is excluded. BFW qvfta�� BACON 1 FARMER; WORKMAN ENG.+.GEPixO d+E�+irv4 trvG MARCUM SM ENGINEERING, LLC eTech Call Center De e r v Scope of Work June 25, 2013 Des Services • Architectural Design • Civil Engineering Design • Structural Engineering Design • Mechanical Engineering Design • Working Drawings • Soils Investigation and Report • Construction Administration/Inspections Division 1— General Conditions • Project Management • On Site Supervision • Daily Clean Up • Final Cleaning • Layout • Tools and Equipment • Temporary Facilities • Builder's Risk Insurance • Payment and Performance Bond • Building Permit Division 2 — Site Work • Earthwork -- Cut and Fill as Necessary to Balance the Site • Storm Sewer • Asphalt Paving — 8" Compacted DGA and 3" Asphalt • Post Formed Concrete Curbs • 4" Concrete Sidewalks Utilizing 4,000 psi Concrete • 6" Concrete Entrance Utilizing 4,000 psi Concrete • 6" Concrete Dumpster Pad Utilizing 4,000 psi Concrete • Topsoil Replacement • Seeding • Landscaping Allowance of $10,000.00 Division 3 — Concrete • Concrete Foundations as Shown Utilizing 4,000 psi Concrete • 4" Concrete Floor Slab Utilizing 4,000 psi Concrete Division 4 — Masonry • Brick Veneer on Exterior Walls Including $350.00/1,000 Brick Allowance - MARCUM WV ENGINEERING, LLC BACON 1 FARMER j WORKMAN ENlR�NEENtYE b �ESiNn NIC Call Center Design Build Servic Division 5 — Structural Steel • Pre-engineered Structural Steel Framing • 22 ga. Steel Deck Division 6 — Wood and Plastics • Rough Carpentry Including Roof Blocking and Miscellaneous Blocking • Reception Desk — Custom *Designed and Built • Plastic Laminate Break Room Counter as Shown • Plastic Laminate Restroom Vanities Division 7 — Thermal and Moisture Protection • R-38 Simple Saver Insulation System in the Roof • R-19 Batt Insulation in the Walls • 2" Exterior Insulation and Finish System • 60 -mil. TPO Membrane Roofing with 20 year Warranty • Sheet Metal and Flashing • Joint Sealants Division 8 — Doors and Windows • Exterior Doors to be Hollow Metal Doors and Frames • Interior Doors to be Solid Core Wood Doors and Hollow Metal Frames • Aluminum Entrances and Storefronts • Aluminum Windows • Finish Hardware • Glass and Glazing • Restroom Mirrors Division 9 — Finishes • Exterior Walls to be 12 ga. Metal Studs, 6" Batt Insulation, DensGlass Sheathing, 5/8" Drywall • Non -Load Bearing Interior Walls to be 25 ga. Metal Studs, Sound Batt Insulation, 5/8" Drywall both Sides • 2' x 2' Revealed Edge Acoustical Ceilings with 15/16" Grid at All Public Areas, Offices, Training Areas, and Conference Rooms • 2'x 2' Square Edge Acoustical Ceilings with 15/16" Grid at All Other Areas • Ceramic Tile in Restrooms and Vestibule • Resilient Floor Tile in Break Room, Comm./Elec. and Storage Closets • Carpeting in Waiting, Reception, Offices, Conference Rooms, Training, TA Staff, TA Testing, and Production Area b Painting as Necessary Division 10 — Specialties • Toilet Partitions as Shown • Interior Signage as Required • Fire Extinguishers and Cabinets per Code BFW BACON I FARMER( WORKMAN ................. -"._...._........ _.......... _. ENGNEEflINO 6 TFSTIN9 INC kj1W MARCUM WIL ENGINEERING, LLC "„.,- n ,w.,-]. u' —_L_j_�.lue� .. , _ . — _[6 li _ c_ . . _. __ i .. uL Id:— Tec ter Design Build Sery • Toilet Accessories as Required Division 15 — Utilities • 2-1/2" PVC Domestic Water Service Piping Including 2" Meter • 6" Ductile Iron Pipe Underground Fire Main Service Including Tap and Bore Under McCracken Boulevard • 4" PVC C-900 Pipe for the Remote Fire Department Connection • 4" Exterior PVC Sanitary Sewer Piping Including Tap Fee • Natural Gas Piping Division 1S — Mechanical • Plumbing Fixtures — Flush Valve Type Toilets and Urinals • Copper Domestic Water Piping • PVC Sanitary Sewer and Vent Piping • Natural Gas Piping • Rooftop Package HVAC Units • Ductless Split Heat Pumps • Computer Room Air Conditioner • Exhaust Fans • Supply, Return and Exhaust Ductwork System — Including Duct Sock in Production Area • Refrigerant Piping • Seismic Material and Calculations on All Duct, Pipe and Equipment • Mechanical Insulation • DDC Controls • Certified Air Balance • Wet Automatic Fire Sprinkler System Division 16 — Electrical • Switchgear Package • Lighting Fixtures • Site Lighting • 800A Power Company Feed • Transformer Pad • Aluminum Wire and MC Cable per Code • Cable Tray for Data Wiring • Fire Alarm System • Temporary Lighting • Temporary Power Exceptions to the Specifications • Water heaters will be electric. Natural gas is only utilized for rooftop HVAC units. • Sub -panels and breakers shall be provided by the Contractor in lieu of the Tenant as referenced. • Fire Alarm shall be provided complete by the Contractor in lieu of the core and shell as referenced. BFW MARCUM ENGINEERING, LLC BACON I FARM ..... .. . ........... _ e'N01TIEENIN06TE9TINp WC Tech Call Center Design Build Services • Height of the building is approximately 20'-0" to the roof line in lieu of 24'-0" clear height as referenced. • A 4" thick concrete slab will be provided in lieu of the referenced 6" thick concrete slab. • A 2-1/2" water line is required for the facility in lieu of the referenced 2" water line. • A 4" sanitary sewer will serve the facility in lieu of the referenced 6" sanitary sewer line. • Two (2) 6" under -slab, longitudinal sanitary lines are excluded. • Two (2) 1" under -slab, longitudinal domestic water lines are excluded. • Fire pump is excluded as that it is not required for standard 100% coverage. • Communication systems (jacks, cabling, racks, patch panels, switches, routers, phones, etc.) are excluded. • Emergency generator is excluded. 19FW ZA�. BACON I FARMER I WORKMAN ENGINEEPING 6 TESTINP. IPC MARCUM bdW ® ENGINEERING, LLC 4 A&K Construction, Inc. COMMERCIAL & INDUSTRIAL CONTRACTORS Call Center Design Build Services June 25, 2013 Value Engineering Items Original Proposal - Brick Veneer and EIFS Accents Alternate $ 4,180,000.00 Value Engineering Items 1. Reduce the height of the building. (113,249.00) 2. Reduce concrete slab thickness to 4" in lieu of 6". (32,588.00) 3. Install feeds to cubicles from power poles in lieu of underground. (15,473.00) 4. Eliminate the generator. (144,416.00) 5. 6. Eliminate the UPS. Eliminate the sound masking system. (77,366.00) 7. Reduce the cost of the lighting package. (20,631.00) (60,861.00) 8. Reduce the cost of the floor finishes. (19,119.00) 9. Eliminate the folding partition. (12,379.00) 10. Eliminate the turnstile. (26,476.00) 11. Eliminate the appliances. (7,284.00) 12. Eliminate the window blinds. (3,168.00) 13. Install a wet sprinkler system in the MDF/UPS rooms in lieu of (26,397.00) a clean agent system. 14. Eliminate the back up computer room HVAC unit. (32,144.00) 15. Eliminate the ceilings in Production Area and Break Room. (65,449.00) 16. Eliminate the data cabling allowance. (165,000.00) 17. Install chemical fire suppression in the MDF room. 23,397.00 18. Add back-up HVAC system for MDF room. 15,144.00 19. Eliminate the DDC controls. (11,000.00) 20. Use metal panel accents on the exterior in lieu fo EIFS. (19,000.00) 21. Additional savings in finishes. (10,000.00) 22. Eliminate 100 parking spaces. (81,541.00) 23. Add installation for owner supplied emergency generator, transfer switch and UPS. 50,000.00 24 Savings for Schematic Floor Plan "C". (29,000.00) Revised Total $ 3,296,000.00 IU. CIIIOWCSycadf]cc:a`�.i;fci< :a�f„�:..yr�. I .7 :% ') ��-i� Equ•:11 Opc• ndrunifv Err,,.^ioyei 'SCI EMATI -C -F70-0 FP LA N A K Consti-ticiion, hic. NEW FACILITY FOR TELE EC H f �